River Earthwork 1 Contract (hereinafter referred to as Party A): _ _ _ _ _ _
Contractor (hereinafter referred to as Party B): _ _ _ _ _ _
In accordance with the Contract Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness, honesty and credibility, both parties reached an agreement through consultation and jointly abided by it.
I. Overview of the Project
Project name: _ _ _ _ _ Project location: _ _ _ _ _ _ _
Second, the scope of the contract of carriage
Scope of transportation contract: transportation of earth and stone, construction soil slag, construction sand and other materials involved in this project.
Third, the construction cycle
Construction period of this project: according to the construction period determined by Party A, cooperate with Party A's project schedule to plan the construction period. Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Four, the way of contracting and contract unit price
For off-site transportation, the bucket loading capacity of _____m3 heavy dump truck is RMB per train. The unit price refers to all expenses of vehicles provided by Party B that have been recognized as qualified by relevant government management departments and have relevant certificates, from starting at Party B's parking place to leaving the site after loading at Party A's construction site, including but not limited to vehicle fuel, vehicle maintenance, vehicle depreciation, salaries of Party B's drivers and managers, living expenses of Party B's drivers and managers, all insurance premiums, all expenses for ensuring safety and spoil fees.
Verb (short for verb) pays the price.
Take every _ _ _ train as a settlement cycle, and pay _ _ _% of the price to Party B within _ _ _ days after the examination and approval, and the balance shall be paid within _ _ _ days after the completion of the project.
The main responsibilities of both sides of intransitive verbs
(1) Party A's responsibilities:
1, responsible for the overall coordination, command and management of on-site construction, timely payment of freight and settlement procedures.
2. Be responsible for the construction conditions of the construction site and ensure the normal transportation of Party B after entering the site.
3, responsible for the loading of soil and stone.
4. Be responsible for the safety disclosure and safety education of Party B's personnel.
(II) Party B's responsibilities:
1. Organize vehicles to enter the site on time according to Party A's requirements, and ensure that the vehicles are in good condition, with complete and valid certificates and complete insurance procedures. And is responsible for vehicle maintenance, maintenance and driver equipment.
2. Party B shall submit a copy of the driver's license, driving license, road transport certificate, construction waste transport certificate, insurance policy and other relevant documents of each vehicle entering the site to Party A for the record (the original is inspected by Party A). Consciously abide by the relevant laws and regulations of the state, and it is strictly forbidden to drink and drive fatigue.
3. Party B shall be responsible for all traffic accidents or safety accidents inside and outside the construction site, and Party A shall not bear any direct and joint liability.
4. All vehicles of Party B on the construction site must travel in strict accordance with the route designated by Party A.. In case of violation, all safety accidents or traffic accidents should not only be fully responsible, but also bear all other losses caused by the accident.
5. Party B must educate drivers and passengers to abide by the principle that vehicles are overloaded and not started, and vehicles with diseases are not on the road. If the loading machinery dispatched by Party A is overloaded during loading, the driver and management personnel of Party B must immediately stop and refuse to start the vehicle. If Party B fails to do this, it will still drive the vehicle away from the loading operation surface, and all responsibilities shall be borne by Party B. ..
6. Before the expiration of the contract, Party B shall not breach the contract under any excuse, and Party B shall not terminate the contract halfway without Party A's breach of contract. If Party B terminates the contract by itself, Party A shall regard the remaining _ _ _% of the price as the economic compensation directly deducted by Party B, and Party B shall not have any objection.
7. Party B must arrange transportation vehicles reasonably in strict accordance with Party A's requirements for daily earthwork transportation trips. Party A's requirement for the number of earthwork transportation trains for this project is more than _ _ _ trains per day (except for weather reasons). If Party B fails to complete Party A's transportation requirements every day, Party A will find out the reasons unilaterally. If it is really due to policy restrictions and the reason of the spoil ground (the spoil ground is agreed to be an Anliang residual mud and muck storage ground), Party A can forgive Party B ... All other reasons are not adopted by Party A, which is regarded as Party B's breach of contract. Once Party B breaches the contract, Party A has the right to arrange other transportation units to transport earthwork, and the resulting difference shall be compensated by Party B and deducted directly from the progress payment, until the contract is directly terminated after deducting the remaining amount of Party B, and Party A reserves the right to pursue all legal responsibilities of Party B. ..
8. If all the property of Party A is damaged by Party B's transport vehicles at the construction site, it will be repaired according to the price.
Seven. responsibility for breach of contract
1. The above terms are legally binding, and both parties shall abide by and implement all terms of this contract. In case of breach of contract, it shall be handled in accordance with the provisions in the breach of contract clause of the Contract Law. All economic losses caused by this must be borne by the breaching party.
2. Dispute settlement: Party A and Party B treat each other sincerely and settle the dispute through consultation. * * * If no settlement can be reached through negotiation, a lawsuit can be brought to the local court.
3. Matters not covered shall be settled by both parties through negotiation, and the supplementary agreement shall be in written form. The supplementary agreement has the same legal effect as this contract.
4. This contract is made in duplicate, one for each party, and it will take effect after being signed. I hope * * * will abide by it. After the transportation project is completed or the contract expires, there is no dispute between the two parties, and the contract will be automatically terminated after the freight is paid.
Party A (official seal): _ _ _ _ _ _
Party B (official seal): _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
River earthwork construction contract 2 Employer: _ _ _ _ _ (hereinafter referred to as Party A) Contractor: _ _ _ _ _ _ (hereinafter referred to as Party B)
In accordance with the Building Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reached an agreement on the following construction projects and concluded this contract.
I. Overview of the project: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
1. Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
2. Scope of contract: Earthwork transportation of the above projects.
Second, the contract price:
1. Transportation price: the starting price is RMB, and the starting price is RMB.
2. Settlement method: The settlement of this project is based on the actual number of vehicles determined by Party A and Party B and the unit price agreed in this agreement, and the oil fee is paid once a month according to the completed engineering quantity.
3. The owner shall pay the project payment one month after confirmation.
Three. Rights and obligations of Party A:
1. Provide construction site to maintain normal vehicle transportation.
2. Provide Party B with necessary transportation conditions.
3. Pay the contract price according to the time limit and method agreed in the contract.
4. When the project quality fails to meet the agreed standard, Party A has the right to require Party B to continue the construction and transportation, and work overtime reasonably until it reaches the agreed standard.
5. During normal construction, Party B shall unconditionally obey Party A's command and mobilization at the construction site. If a vehicle disobeys the command, Party A has the right to deduct 10% of its monthly freight as a fine.
Four. Rights and obligations of Party B:
1. Provide transportation vehicles needed for construction.
2. Party B shall sign labor contracts with team members, and collect copies of drivers' relevant certificates (driver's license, driving license and ID card) and submit them to Party A for filing.
3. Complete the contracted project on schedule.
4. Party B shall abide by the management regulations on production safety in engineering construction, organize the implementation in strict accordance with safety standards, accept the supervision and inspection of industry safety inspectors at any time, and take necessary safety protection measures to eliminate hidden dangers of accidents.
5. Party B shall be responsible for the accidents and expenses caused by Party B's ineffective safety measures, and Party A shall not bear any responsibilities and expenses.
6. Due to the needs of the project, Party B shall replenish vehicles on time, and Party A has no right to dispatch vehicles from outside.
Verb (abbreviation of verb) This agreement is signed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A (signature): _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
3 Party A's (hereinafter referred to as Party A) river earthwork construction contract: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B (hereinafter referred to as Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness, honesty and credibility, Party A decides to entrust the earthwork excavation of Jiangsu Yaken Project to Party B.. In order to standardize the management and clarify the responsibilities, this contract is specially signed through negotiation between both parties, and both parties agree.
I. Overview of the Project
Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Second, the scope and content of project contracting
1 contract scope: all excavation contents of the office building, workshop, warehouse, pool, oil tank foundation and fence foundation of this project, indoor soil borrowing after foundation completion, soil borrowing after pipeline installation of the main building project completion, and sporadic machine shifts of excavators are needed during the construction period 10 hour.
2. Contract content: Organization, management, operation, maintenance and fuel supply of machinery and equipment and transport vehicles used for earthwork excavation; The determination of the road that transport vehicles will pass through (including all costs involved in passing through the road), the cleaning and coordination of road sanitation involved in vehicle transportation, the coordination of all departments except the projects involved in Party B's construction (including all costs to be paid), and the safety during mechanical operation and vehicle transportation.
Third, the term of the contract.
The contract period shall be synchronized according to the total project progress. In case of rain or other force majeure, the construction period will be postponed.
Fourth, the project quality (acceptance criteria)
Determined by the project department according to the drawing design requirements.
Verb (abbreviation for verb) The responsibility of both parties.
Party A's responsibilities
1, responsible for engineering quantity verification, technical disclosure and construction setting-out.
2. Be responsible for timely payment of project funds as agreed in the contract.
3. When the transport vehicle comes out, it is responsible for providing water for car washing.
4. Party A is responsible for coordinating the surrounding relations, ensuring that there is no obstacle or interference in the construction process and ensuring the normal construction of the project.
Party B's responsibilities
1. Party B is responsible for reasonably organizing personnel, machinery and vehicles for excavation and transportation according to the requirements of Party A's construction period, and completing the work content on time and in quantity.
2. During the construction period, Party B shall bear all safety responsibilities, and Party B must ensure civilized and safe construction during the construction process, and the expenses involved shall be borne by Party B. ..
3. Party B is responsible for the maintenance and repair of construction machinery and vehicles, and provides fuel to ensure the normal operation of construction machinery and vehicles.
4. If Party B causes personal or property losses to himself or a third party due to improper construction, dereliction of duty or illegal operation, Party B shall bear all responsibilities arising therefrom.
Unit price and payment method of intransitive verbs
1. Earthwork quantities and sporadic projects involved in the requirements shall be contracted by _ _ _ _ _ _ _.
2. Payment method: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Seven. responsibility for breach of contract
After the signing of this contract, if either party fails to perform its obligations under this contract, it shall not only cause economic losses to the other party, but also compensate the other party for the liquidated damages of RMB.
Eight. For matters not covered in this contract, supplementary terms can be signed by both parties through consultation, and the supplementary terms have the same legal effect as this contract.
Nine. After the signing of this contract, if Party B has any objection to this contract, it can be settled by both parties through consultation. If negotiation fails, the case may be submitted to the local arbitration commission for arbitration or brought to the local people's court.
X this contract is made in duplicate, one for each party. It will take effect after being signed by both parties, and will automatically become invalid after the project is completed and the project price is settled by both parties.
Party A (signature): _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
The fourth contract of river earthwork: _ _ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
Party A and Party B reach an agreement on the basis of equality and mutual benefit in accordance with the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations and in combination with the specific conditions of this project. In order to clarify the rights, obligations and responsibilities of both parties in the performance process, this contract is specially formulated for Party B to undertake the earthwork of Party A for both parties to abide by.
I. Overview of the Project:
Project name:
Project location:
Project content:
2. Contract method and price: The total price is RMB/m3 (including all expenses).
Three. Time limit for a project: All projects under this contract will start on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
1, forced to stop work due to natural disasters or other force majeure reasons;
2. The construction cannot be continued because Party A proposes a change plan or changes the construction drawing;
3. Due to Party A's failure to provide drawings, materials, equipment and other agreed conditions on schedule, the equipment does not meet the requirements of the specification, and Party A is forced to stop work or fail to construct smoothly.
Fourth, the project quality and warranty
1. Project quality requirements: According to the relevant regulations and the stipulations of this contract, the project quality has reached the qualified standard after inspection by Party A, the owner, the supervision engineer and relevant quality supervision departments;
2. Party B must carry out the construction in strict accordance with the construction drawings, the explanatory documents provided by Party A, the relevant engineering specifications, procedures and standards promulgated by the state, the technical disclosure documents of both parties and the written instructions of Party A, and accept the supervision and inspection of Party A, the supervisor and the owner's representative;
3. Party B shall provide relevant technical materials at any time according to Party A's requirements, such as copies or originals of materials, factory certificates of equipment and test reports (materials provided by Party B);
4. Party A can check the progress and quality of the project operation at any time. If Party B's construction does not meet the requirements agreed by both parties or relevant technical specifications, Party A may require Party B to stop work or rework, and the losses and rework expenses caused by the stop work or rework shall be borne by Party B;
5. After the project completion acceptance reaches the qualified standard agreed in this contract, Party B shall bear the warranty responsibility and expenses in accordance with the relevant national regulations on project warranty.
Verb (abbreviation for verb) The responsibility of both parties.
Party A's responsibilities
1. Pay the project payment (including progress payment and settlement payment) within the time limit agreed in this contract;
2. Assist Party B to handle the relevant construction application procedures and coordinate the relationship with the local government and residents;
3. Responsible for the coordination and command of on-site construction, send technicians to supervise and inspect the progress and quality of the project, and go through the visa formalities for the acceptance of the intermediate project;
4. Provide Party B with drawings and materials related to this contract;
5. Before starting work, make technical disclosure of this project and related projects to Party B;
6. Assist Party B to handle the temporary residence permit and employment procedures for construction personnel;
7. Check the safety education certificate and training certificate of Party B's personnel entering the site;
9. Be responsible for organizing relevant testing work, and Party B shall organize appropriate personnel to cooperate with Party A in testing work;
10. Be responsible for guiding Party B to fill in relevant construction materials.
Party B's responsibilities
1. Obey the on-site command and management of Party A, the supervisor and the owner;
2. Obey the quality, safety, progress and civilized construction management of Party A's site; Accept the rewards and punishments of Party A according to the established reward and punishment system of the project progress, and be responsible for the construction quality, safety, progress and civilized construction of the project undertaken;
3. Organize the construction on time, and complete all the work agreed in this contract with good quality, quantity, safety and time and deliver it to use;
4. Be responsible for preparing the organization construction plan according to the relevant information of the construction contents of this contract (such as drawings and Party A's instructions, etc.). ) and submit it to Party A for approval;
5. Formulate appropriate engineering quality and safety assurance measures;
6. Conduct safety education for construction personnel to prevent safety accidents.
Settlement and payment methods of intransitive verbs:
1. Settlement of actual completed quantities confirmed by both parties * * *;
2. From the effective date of this contract, Party A shall pay Party B the material preparation fee and construction fee in one lump sum within _ _ _ _. During the project, Party A shall allocate progress payment to Party B according to the progress of the project. Before the completion acceptance of the project, _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ refers to
3. Party B must provide the Jian 'an invoice approved by the tax authorities, otherwise Party A has the right to refuse to pay and the construction period will not be postponed.
Seven, Party B must obey the supervision and management of Party A's site representative and supervision engineer, and Party A must give necessary assistance and support to Party B in the construction.
Eight. Party B shall do a good job in production safety. In case of safety accident, the expenses arising therefrom shall be borne by Party B. ..
9. Party B must transport the earthwork to the place designated by Party A, and shall not transport it abroad or discard it at will.
X. Handling of breach of contract: If Party B fails to complete the project on the completion date agreed in this contract, it will be fined RMB 500 yuan for each day of delay. If Party A fails to pay the project payment on time and in quantity as agreed in this contract, Party A shall pay interest to Party B according to the bank loan for the same period.
XI。 Dispute settlement: In case of any dispute between the two parties, Party A and Party B shall settle it through friendly negotiation; If negotiation fails, a lawsuit may be brought to the people's court.
12. For matters not covered, both parties may conclude supplementary terms through consultation as supplementary contracts to this contract, which have the same legal effect as this contract.
13. Both parties agree to take the project list and other documents related to this project as annexes to this contract, which are an integral part of this contract and shall be observed by both parties.
Fourteen This agreement shall come into effect after being signed or sealed by both parties, in duplicate, with each party holding one copy.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
5 Party A's river earthwork construction contract:
Party B:
According to the Construction Law of People's Republic of China (PRC), Regulations on Construction and Installation Engineering, Regulations on Quality Management of Construction Engineering and Regulations on Safety Management of Construction Engineering, combined with the specific matters of this project, and based on the principles of mutual benefit, fairness and justice, Party A and Party B reached the following agreement through friendly negotiation for common compliance.
I. Project Location:
West of Yingbin Road and north of Xi 'an Road. Earthwork excavation and transportation in Hong Kong City Phase I site.
Second, the scope and content of the contract:
Site earthwork excavation and transportation.
Third, the way of contracting:
Excavation and off-site transportation (Party B shall be responsible for excavators and all other earth-moving equipment).
Four, the project contract price and calculation method
According to the measured earthwork quantity, the earthwork quantity is calculated, and the 24 yuan per cubic meter is transported outside the site.
Five, quality requirements:
According to the national acceptance standard, the construction is qualified.
Six, the project payment method:
30,000.00 yuan will be paid after the completion of earthwork excavation and transportation, and the balance will be paid at the end of _ _ _ _.
Seven, the construction period
Eight. Party A's responsibilities
Responsible for measuring earthwork elevation
Nine. Party B's responsibilities
1. Party B shall go through the earthwork excavation and transportation procedures such as muck certificate, land unloading, urban construction administrative law enforcement fines, vehicle transportation, etc., and all the expenses incurred shall be borne by the contractor and have nothing to do with Party A. ..
2. Party B is responsible for all traffic accidents of transport vehicles, and any matters arising from digging and transporting earthwork have nothing to do with Party A. ..
3, the contractor in strict accordance with the provisions of the construction site management, disclosure about safety and environmental protection, abide by the relevant laws and regulations, offenders will be punished in accordance with the relevant provisions, the resulting safety and quality accidents shall be borne by the contractor, and shall be liable to the employer.
4. Party B must cooperate with Party A's management personnel to dig according to the digging elevation provided by surveying and mapping personnel.
5. Party B shall cooperate with Party A for civilized construction.
6. Party B shall be responsible for all safety casualties in the construction of earth-moving machinery, which has nothing to do with Party A. ..
7. Party B shall complete the project construction in strict accordance with the requirements of the contract period. If the construction period is delayed due to Party B's reasons, Party A has the right to terminate the contract without settling the amount of excavation that has occurred. Therefore, Party B shall compensate for the negative impact and economic losses caused to Party A. ..
X. Settlement of disputes
In case of any dispute, both parties shall settle it through negotiation; if negotiation is inappropriate, it shall be settled through legal procedures.
XI。 This agreement is made in duplicate, one for each party, and shall come into effect after being signed by the representatives of both parties.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
6 Party A's river earthwork construction contract: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
According to the Contract Law of People's Republic of China (PRC) and relevant regulations, Party A and Party B, based on the principle of mutual benefit, have reached the following contract terms through friendly negotiation on the transportation of earthwork filling project contracted by Party B to Party A, which shall be strictly observed by both parties.
I. Overview of the Project
1, project name: _ _ _ _ _ _
2. Project location: _ _ _ _ _ _
3. Total amount of the project: _ _ _ _ _ _.
Second, the engineering transportation distance and price
The construction period is one year (weather working days)
Content: Party A will contract the earthwork loading and transportation project legally contracted by Party A to Party B, and transport the earthwork to the place designated by Party A. ..
1, the vehicle is designated as _ _ _ _ cubic rear eight-wheeler (specifications are _ _ _ meters, _ _ _ meters, _ _ _ meters or _ _ _ _ meters respectively). When Party B's vehicle is loaded, if the carriage is damaged by _ _ _ _ _ cm, the loader shall compensate. When dumping earthwork, if there are so many stones that the trunk can't be emptied, stop there, and Party A will make up 400 yuan every hour.
2. The transportation distance of the transportation route is _ _ _ _ kilometers, and the initial unit price of earthwork per vehicle (zero kilometers) is RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
3. The vehicle transportation fee does not include tax. Any taxes and fees shall be borne by Party A..
4. Party A shall provide a forklift to help solve the problem of dangerous tilting and sinking when the vehicle is loaded with earthwork. Party A shall be equipped with sufficient loading machinery. If Party B's vehicles are idle due to lack of machinery, each vehicle shall be paid a shift fee of RMB per hour.
Three. Rights and obligations of Party A and Party B
1. Payment method: one day is a billing cycle, that is, once a day, and the bill is paid in cash at noon the next day. Party A shall not default to Party B for any reason. Otherwise, Party B has the right to stop the operation and investigate the economic losses caused to Party B by Party A .. RMB _ _ _ _ _ _ _ per vehicle per day.
2. After Party B's vehicles enter the site, they must obey the management of Party A. If there is no justifiable reason, Party B shall not stop work or leave the site halfway, otherwise Party B shall compensate Party A for all the economic losses caused thereby.
3. Party B shall enter the site for construction according to the arrangement of Party A, and Party A shall assist Party B's driver and staff to rent accommodation, and Party A shall bear the water and electricity. Party B's motorcade entry formalities shall be handled first and deducted from the oil settlement project provided by Party A..
4. Party A is responsible for road maintenance and maintenance of transportation roads to ensure smooth roads. And arrange _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
5. Party A must ensure that the local traffic police, operation, road administration, environmental protection, streets, local villagers and other relevant departments do not seize or detain the vehicle. If the car is detained, Party A shall be responsible for all the expenses of the fine, because if the car is detained for more than 24 hours, it will be regarded as delayed work, and each car will be compensated according to the contract.
6. Oil prices fell by RMB _ _ _ _ _ _ _ _ _ _ _
7. Under normal circumstances, if Party B's vehicle stops for one day without special reasons, Party A shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
8. Party A is responsible for rock blasting (each piece does not exceed _ _ _ to _ _ _ _ kg), which will not affect the loading. In addition, the management fee of Hutoushan (Toutou) floor materials and any expenses required by villagers shall be borne by Party A. ..
9. Any transportation safety accident during the construction period shall be the responsibility of Party B, which has nothing to do with Party A, and Party A is only responsible for mediation.
10. After each car of Party B enters the site (after the formalities are completed), each car of Party A needs to borrow an entrance fee of 1000 yuan, which will be deducted in proportion _ _ _ days after entering the site.
Four. Matters not covered in this contract shall be signed by both parties through consultation. Party A must pay Party B the project transportation fee from the commencement date to the completion of the project. This agreement is made in quadruplicate, with Party A and Party B holding two copies respectively, all of which have the same legal effect. This contract shall come into effect after it is signed.
Verb (abbreviation of verb) In case of any dispute arising from the performance of this contract, both parties shall settle it through consultation. If negotiation fails, it shall be submitted to labor arbitration on the construction site or brought to the local people's court for public prosecution.
Special agreement on intransitive verbs:
Party B shall deduct _ _ _ _% of the project payment for the first ten days as the project deposit according to the total daily settlement fee, and repay it in one lump sum after the project is completed.
Party A (official seal): _ _ _ _ _ _
Party B (official seal): _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _