↓↓↓↓↓ Click to get more "engineering contracts" ↓↓↓↓
★ Self-built house construction contract ★
★ Contract and material contract ★
★ Road engineering contract ★
★ Construction contract of construction project ★
Simple engineering construction contract 1
Party A: Nanyuan New Village 1# Comprehensive Building
Party B: (Masonry)
Party A will contract the masonry works and decoration sub-projects of Nanyuan New Village 1# Complex to Party B for construction. In order to clarify the responsibility of both parties to complete the construction task on time and with good quality, the following agreement is reached through friendly negotiation between both parties:
1. Scope of contract: all masonry, concrete, decoration, prefabricated structure installation and other projects within the design scope of drawings.
Second, the way of contracting: the contractor does not package materials.
Three. Contract price: subject to the interior construction area, and settled at () yuan/m2 construction area.
Four. Quality requirements: Party B must carry out the construction in strict accordance with the design requirements of the drawings, and the project quality must meet the acceptance standards of the current national standards. Unqualified items must be rectified or reworked, and an economic penalty of more than 100 yuan and less than 1000 yuan shall be imposed. Concrete workers are not allowed to have honeycomb holes, which are not dense, and the penalty is 100 yuan, and the decoration is not vertical and uneven 100 yuan.
Verb (abbreviation of verb) safety requirements: We must strictly abide by the safety management norms and various safety production management systems of the project, and conduct safety training and education for employees. Without training, you are not allowed to work. In the process of construction, the safety operation rules must be strictly observed, and the safety accidents caused by not following the operation rules shall be borne by Party B, which has nothing to do with Party A, and an economic penalty of more than 100 yuan and less than 500 yuan shall be imposed.
The penalty method of intransitive verbs: the main body of this project is divided into seven stages: foundation one, two, three, four, five and six, and capping. After the completion and acceptance of each stage, the main body will pay 80% of the salary at this stage, and after the completion and acceptance of internal and external decoration, 80% of the total amount of wages will be paid, and the remaining 20% will be paid as the maintenance deposit of the amount of works, and all quality problems will be settled within one year.
Seven. Duration: Party B must carry out the construction in strict accordance with Party A's construction schedule, reasonably arrange the operation time and work overtime to ensure the smooth completion of the construction schedule.
Eight, other requirements:
1. After each working procedure or subdivisional work is completed, Party B must clean up the site after work and keep the materials neatly stacked. It is forbidden to urinate anywhere on the construction site. Once found, 50 yuan will be punished.
2. After all kinds of tools are purchased by Party A, they shall be kept and used by Party B.. Party A is responsible for the maintenance, and all the tools will be returned to Party A after the project is completed, and compensation will be paid according to the price.
3. During the construction period, Party B shall closely cooperate with each team and obey the unified management of the project department, and it is forbidden to fight and other undesirable phenomena.
Nine. This agreement shall come into effect as of the date of signature by both parties. If either party violates the above terms, it is a breach of contract, and both parties have the right to terminate the agreement. In case of breach of contract due to Party B's reasons, Party A may refuse to pay part of the wages of Party B's completed project funds; In case of shutdown or shutdown or replacement of materials due to Party A's reasons, Party A shall pay part of the wages of the completed project to Party B as agreed, and bear the corresponding shutdown losses.
X this agreement is made in duplicate, one for each party. It shall take effect from the date of signature, and shall terminate on the date when the project is completed and accepted and the wages are settled in full.
Party A's representative: Party B's representative;
date month year
Simple engineering construction contract 2
Employer:
Contractor:
According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, both parties follow the principles of equality, voluntariness, fairness and good faith, and the contractor implements the general construction contract for the Jinxiu Jiangnan residential area project in Linying County, Henan Province, and the following construction agreement is signed by both parties through consultation:
I. Overview of the Project:
1, project name:
2. Project location:
3. Project content: 1# building and 2 * * * building, with a total construction area of about 50,000 square meters.
4. Structural form: brick-concrete structure.
Second, the way and scope of project contracting
1. Contracting method: contracting for work and materials.
2. Scope: Civil engineering and water and electricity installation works in the construction drawing of this project.
Third, the construction cycle
1. Commencement date: 20_ (subject to commencement report); Completion date (preliminary inspection): year month day.
2. The total construction period is 330 calendar days; Under special circumstances (such as power failure for more than half a day), the construction period will be postponed with the consent of the Employer.
3. The contractor shall complete the construction within the time limit agreed in the contract, and pay the liquidated damages of 500 yuan RMB/day (except for force majeure) to the employer for each day of delay; If the Contractor completes the project ahead of schedule, the Employer will reward the Contractor with RMB 500 yuan/day for each day ahead of schedule.
Fourth, the quality acceptance
1, the project quality agreed in this contract must reach the qualified grade standard;
2, the project supervision, according to the current national acceptance specifications and procedures for construction and inspection. The contractor must carry out the construction in strict accordance with the drawings and meet the requirements of relevant national codes, standards and mandatory provisions. Obey the supervision and guidance of the site engineer authorized by the supervisor and the employer, rework the unqualified division and subdivisional work in time until it is qualified, and all economic losses caused by rework shall be borne by the contractor.
Verb (abbreviation for verb) contract price and payment
1. Settlement price of this project: calculated according to the construction area, it is tentatively set as 900 yuan RMB per square meter (increased project cost, such as material confirmation price, design change, engineering change contact sheet, engineering contact sheet (letter), construction organization design, construction scheme approved by Party A, etc. Not included in the provisional price).
2. The overhead floor of this project is calculated according to the first floor construction area.
3. Material price: 3,800 yuan per ton for steel bars and 320 yuan per ton for cement; During the construction period, if the price change of this material exceeds 3% of the market price, it will be adjusted according to the actual situation.
4, project payment and settlement
(1) This project shall be paid and settled as a single project. 20% of the total price shall be paid within one week after the foundation is 0.000, 15% of the total price within one week after the completion of the second-floor structure of the main body, 15% of the total price within one week after the completion of the third-and fourth-floor structure of the main body, and 15% of the total price within one week after the main body is capped. Pay 10% of the total price within one week after the plastering of the external wall is completed, 10% of the total price within one week after the completion acceptance, and 95% of the total price within one week after the completion acceptance.
(2) After the unit project is completed and accepted, the contractor shall submit a settlement report within 30 days, and the employer shall audit or put forward audit opinions by a third party within 28 days after receiving the settlement report. Within 28 days after both parties reach an agreement, the Employer shall pay 97% of the total project settlement price to the Contractor (leaving 3% as the quality guarantee). The quality guarantee money will be returned in two years, and 2% will be returned within seven days after the date of completion acceptance 1 year, and the remaining 1% will be returned within seven days after the date of completion acceptance.
(3) If both parties disagree, they can report to the competent construction department for mediation according to the nature of the problem. If the Employer fails to give an audit opinion within 28 days after receiving the completion settlement report, it shall be deemed that the project settlement report has been approved and is willing to allocate the project funds according to this settlement report.
(4) If the Employer fails to pay the project settlement price within 28 days after receiving the completion settlement report without justifiable reasons, it shall pay the overdue project payment interest at the rate of 2% per month from the 29th day, and bear the liability for breach of contract. If the settlement cannot be handled within 28 days due to the contractor's non-cooperation, it has nothing to do with the employer.
(5) In order to fully reflect the good cooperation will of both parties, the contractor agrees to pay the developer a deposit of 6,543,800,000 yuan within 654.38+00 days after the formal contract is signed, and the deposit will be returned 50% within seven days after the completion of the second-floor structure of the main body, and all of it will be returned within seven days after the main body is capped. If the deposit is not returned at the agreed time, a penalty of 0.3% of the refundable amount shall be paid for each day overdue.
Six, material procurement
All building materials, all kinds of finished products and semi-finished products within the contract scope are purchased and kept by the contractor. The contractor must strictly control the quality of materials, strictly carry out the procedures of material entry and inspection, and it is strictly forbidden to use materials without factory certificate, quality guarantee or test report and certificate. The quality of all incoming materials must meet the national inspection standards, and can only be used after passing the inspection by qualified building materials inspection departments.
Seven, safe production and civilized construction
1, the contractor shall abide by the relevant provisions of the project construction safety production management, go through the relevant safety production procedures, organize the construction in strict accordance with the safety standards, and accept the supervision and inspection carried out by industry inspectors according to law at any time, and take necessary safety precautions to eliminate potential accidents. In case of quality and safety accidents during construction, resulting in casualties, all legal liabilities and all economic losses arising therefrom shall be borne by the responsible person.
2. The contractor must, in accordance with relevant administrative regulations, codes and standards, and in combination with the actual situation of this project, work out a reasonable and perfect construction organization design and various special construction schemes for production safety, and with the approval of the chief supervision engineer and the engineer authorized by the employer, do a good job in civilized construction and production safety, and strive to be a "safe and civilized standard chemical site".
Eight. others
1 After the contract is signed, the contractor sends Chen Youming's project manager to form the project department, with a complete team to carry out standardized project management, and the operators must hold relevant certificates.
2. In the process of construction, the contractor shall cooperate with the employer to coordinate all local and surrounding relations, and be responsible for surrounding interference according to their respective responsibilities. If the unloading fee occurs, it shall be borne by the employer.
3. When the Employer handles the comprehensive acceptance of construction permit, bidding, sanitation, environmental protection, road occupied by construction, sewage discharge and other projects and the formalities of relevant government departments, the Contractor shall actively cooperate and bear the expenses according to relevant regulations.
4. The electricity and water for the construction of this project shall be provided by the Employer, and the expenses shall be borne by the Contractor.
5. If the Employer proposes to change the original design during the construction process, it shall issue a written notice of change to the contractor 14 days in advance, and the designer shall issue the relevant design change contact sheet. The contractor shall carry out the construction according to the change notice, and the increased project cost shall be paid together with the progress payment, and the construction period shall be postponed.
6. If the Employer fails to pay the project payment within the time stipulated in the contract, it shall pay liquidated damages at the rate of three ten thousandths of the payable for each day overdue.
7. The project payment must be transferred to the bank account designated by the contractor in writing. Other forms of project payment will not be recognized by the contractor.
8. Any dispute arising from the performance of this contract shall be settled by both parties through consultation; If negotiation fails, a lawsuit may be brought to a people's court with jurisdiction.
9. Matters not covered herein shall be discussed separately by both parties.
10. This Agreement is made in octuplicate, with each party holding four copies. It shall take effect after being signed and sealed by the legal representative or his authorized agent.
Owner's (official seal) and Contractor's (official seal) domicile: domicile:
Legal representative:
Authorized Agent: Authorized Agent:
Tel: Tel:
Fax: Fax:
Bank of deposit: Bank of deposit:
Account number: Account number:
Postal code:
Date of signing: Date of signing:
Signing place: Signing place:
Simple engineering construction contract 3
Party A: (hereinafter referred to as Party A) Party B: (hereinafter referred to as Party B)
In order to strengthen the management of construction projects, adapt to the needs of the construction market, strengthen the management responsibility of grading contracting within the company, put an end to the waste and loss of all kinds of building materials, enhance the awareness of quality and safety in construction activities, and complete the task on time, Party A contracts this project to Party B through consultation, with the following terms for compliance.
I. Project Location and Name:
1, project location:
2. Project name:
Second, the way and content of project contracting:
1. Project contracting method: Party B shall be responsible for all tools except tower crane, pole frame and mixer table, including labor cost, safety, quality, construction period and consumption of low-value consumables.
2. Project content: Party B shall carry out the construction within the bricklayer's scope according to the design drawings and the change notice, including the manufacture and installation of foundation concrete, bricklaying, cast-in-place, internal and external plastering, external wall insulation, roof colored tiles, building installation, air conditioning panels, lintels, stairwell tiles and stair toe tiles. According to the requirements of design and construction drawings, all the colored tiles from foundation to roof are completed by bricklayers, and the plastering of external walls must meet the requirements of cement external wall coatings. After completion, the poles and planks upstairs and indoors will be cleaned up to the designated place, and the machine foundation will be cast in situ and bricklaying will be carried out.
Three. Commitment to project settlement and payment methods:
The construction area of the residential area is about square meters, and the total project cost is RMB based on the construction area of RMB per square meter. Based on the actual construction area. This unit price is a one-time fixed unit price, and all labor costs shall be borne by Party B. ..
The above price includes safety protection fee, installation and removal fee and salary of mixer personnel. The project meets the quality requirements. From the foundation completion of each building, 80% of the project progress payment can be paid after two layers of concrete slabs are completed every month, and 95% of the project payment can be paid within three months after the completion acceptance. Funding began after pouring on the first floor.
Party B must complete the project according to the time limit stipulated by Party A's project department, so as to save materials and do a good job in safety. Except the handyman arranged by Party A, this price does not include the handyman's salary.
Four, the project quality acceptance cycle requirements:
1. Engineering quality and inspection and acceptance. Party A and Party B shall cooperate to supervise and inspect the project quality. If quality problems are found, they should be dealt with immediately. If the quality is unqualified due to improper construction, Party B shall be responsible for rework and compensate for the cost of materials. The acceptance of engineering quality shall be carried out in accordance with the construction acceptance specifications and standards.
2. The project was completed before the date of. All masonry works must be completed within 4 months after the foundation of each building is completed, and 500 yuan will be fined for each day of delay, and so on.
Verb (abbreviation for verb) safety matters:
For the safety work of this project, Party A and Party B shall jointly do a good job in safety management, publicity and education on the construction site, strengthen safety inspection and eliminate potential safety hazards in time. Party B must carry out safety education and training for employees, and it is forbidden to engage in illegal operation, drunken construction, work at height with illness, and enter the construction site without wearing a safety helmet or a safety belt. Once found, each person will be fined 100 yuan, which will be deducted from the appropriation of the current month. Do a good job of safety protection. For all safety accidents on the construction site, Party B shall bear part of the economic responsibility and full legal responsibility. If the compensation amount is less than 20,000 yuan, it shall be borne by Party B, and if the compensation amount exceeds 20,000 yuan, both parties shall bear 50% of the excess.
Other matters of intransitive verbs:
1. During the construction period, Party B must accept the management of the owner's construction management personnel, and shall not carry out construction at will, otherwise, Party B shall be responsible for the compensation for the losses caused, which shall be deducted from the contract cost of the current month.
2. During the construction, Party B shall save materials, and shall not waste materials at will, otherwise, it shall pay compensation according to the price. Party A has the right to punish those who intentionally waste materials and deduct them from the contract cost of the current month.
3. Party B shall be responsible for the tools needed by Party B, and other outstanding matters shall be settled by both parties through consultation.
4. If Party B fails to complete the project on time according to the deadline stipulated by Party A's project department, disobeys the management of construction arrangement, and causes hidden dangers, Party A has the right to terminate the contract, deduct the unqualified part and material waste loss from the completed project, and pay Party B 70% of the completed part of the proportional salary, and clear the site. Party B must leave the construction site unconditionally. During busy farming hours, Party B must ensure that more than 30 people are present for construction, otherwise, if there is a shortage of 1 person, each person will be fined 100 yuan per day, and 500 yuan will be fined for delay in construction.
5. Party B shall hold relevant certificates. If Party B is punished by the superior unit for working without a license, Party B shall be responsible for the economic punishment.
6. Party B must carry out civilized construction. Its employees will be fined 100 yuan for quarreling at the construction site once, and 200 yuan will be fined for fighting once, which will be deducted in the current month.
Seven, warranty responsibility:
In order to ensure the quality of the project and safeguard the rights and interests of consumers, Party B must carry out maintenance and warranty on its construction project within the warranty period stipulated by the state. After the acceptance of the project, 5% quality deposit will be deducted from the total project payment. After the project is delivered, there will be no quality problems. Party A shall pay the deposit to Party B. If there is any quality problem during the warranty period, Party B shall be responsible for the maintenance and bear the cost of maintenance materials. If Party B fails to perform the warranty responsibility, Party A has the right to ask others to repair it and pay the expenses in the deposit, such as three or more notices.
Eight. Liability for breach of contract:
Party B must organize personnel to carry out construction according to Party A's time limit for a project and project quality requirements. If the construction period is delayed and the quality acceptance is unqualified, the liquidated damages shall be calculated as 65,438+00% of the total project settlement, which shall be deducted from the settled project payment of Party B, but 500 yuan will be fined for delaying the construction period every day.
Nine. This contract is made in quadruplicate, with Party A holding three copies and Party B holding one copy. It will take effect as of the date of signature by both parties.
Party A (signature and seal):
Party B (signature and seal):
date month year
Simple engineering construction contract 4
Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ (employer)
Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ (the contractor)
Through friendly negotiation between Party A and Party B, in accordance with the Civil Law of People's Republic of China (PRC), the Building Law, the Contract Terms of Construction and Installation Project and relevant local laws and regulations, both parties have reached the following understanding on the construction of this project based on the principles of voluntariness, equality, mutual benefit and good faith:
Article 1: Project Overview
1, project name:
2. Project location:
3, project content and contract scope:
4. Building scale:
5, the project cost:
6. Quality grade: qualified.
7. The design change shall be subject to the change notice notified by Party A in writing and signed and sealed by Party A's representative.
8. Contracting method: This project adopts the contracting method of contracting for labor and materials to ensure quality, time limit, safety and civilized construction.
Article 2 Construction preparation
1. The steel structure components and parts required for this project are manufactured and provided by Party B, and the paint and other accessories are provided by Party B. ..
2. Installation of required equipment, including crane production vehicle, shall be solved by Party B. ..
3. The site, including the site and resettlement site required for the daily life of personnel, shall be provided by Party A. ..
Article 3 Main responsibilities of both parties
1, Party A's responsibility
(1) Party A shall provide Party B with the site conditions required for the project construction on time, coordinate the site conditions, and create conditions for Party B's normal construction.
(2) Party A shall supervise and inspect the progress, quality, construction technology and safety production of the project.
(3) Arrange the living quarters of construction personnel at the designated place.
(4) Unified audit of project budget and final accounts and final settlement.
2. Party B's responsibilities
(1) Ensure that the quality, safety and time limit specified in this agreement are completed on schedule.
(2) submit the list of personnel organized by the project department to Party A within 7 days before entering the site. ..
(3) Within 7 days after entering the site, prepare the project construction organization design and progress plan, and submit them to Party A for approval before implementation.
(4) Submit the project plan, statistics, technology, quality, safety and other relevant information to Party A in time, and accept the inspection and guidance of Party A's functional departments.
(5) If the installation does not meet the requirements, Party A has the right to require Party B to rework, stop work and rectify until it meets the requirements, and all relevant expenses arising therefrom shall be borne by Party B; If Party B fails to rework and rectify in time within the specified time, Party A has the right to point out Party B's appearance, stop the installation and bear all economic losses.
Article 4 Construction period
1, commencement date, completion date, effective construction period of this project, except legal holidays.
2. The commencement date shall be subject to the actual commencement date. See the general project schedule approved by Party A for the schedule of each division and subdivisional work. After the signing of this agreement, Party B will enter the site within years, months and days, and start work at the appointed time.
3. When the actual progress of Party B's construction lags behind the planned progress, Party A and the supervision engineer may issue instructions to Party B to require Party B's personnel and machinery to work overtime. After receiving the instruction, Party B shall work overtime to complete the construction plan on time (overtime hours shall not exceed local working hours standards).
Article 5 Project Quality
1, in strict accordance with the construction drawings and instructions, in accordance with the Technical Specification for Construction Acceptance of Steel Structure Installation Engineering and the Standard for Quality Inspection and Evaluation of Steel Structure Installation Engineering, carefully organize the construction to ensure the project is qualified.
2. If the project quality fails to reach the qualified level, Party B shall be responsible; Reach the qualified level, without reward or punishment.
3, in the construction, must unconditionally accept the inspection, supervision and treatment of Party A and the relevant quality departments.
4. Within the specified warranty period, Party B shall carry out maintenance for free.
5. The project undertaken by Party B shall be constructed and managed in strict accordance with the current relevant national building regulations, construction specifications, standards and local documents. If the acceptance of the project is unqualified, Party A has the right to claim compensation from Party B, and all losses caused thereby shall be borne by Party B. ..
Article 6: Civilized and safe production
1, the construction site must meet the provisions of the provinces and cities on safe and civilized construction.
2, civilized construction requirements according to the location of the construction site "civilized construction on the construction site inspection scoring rules".
3. During the construction period, we must pay attention to safety in production, strictly abide by the relevant provisions of safety in production, and abide by the labor and employment regulations. Party B shall take full responsibility for any accident on the construction site.
Article 7: Payment and settlement of project funds
1. Both parties agree to settle accounts according to.
2. Party A shall be responsible for the three links and one leveling on the construction site.
The water and electricity expenses incurred in the construction shall be borne by Party B (the domestic water and electricity expenses of the subcontractor shall be borne by the subcontractor, and the expenses incurred shall be collected by Party B according to the facts).
Article 8 Contract performance bond
1. After Party A and Party B sign this agreement, Party B's personnel will enter the site, and Party B will pay Party A a performance bond of RMB 1 10,000 yuan.
2. If the project cannot be started on time due to Party A's reasons within the agreed commencement time, the construction period may be postponed. When Party A has the conditions to start the project, this project agreement will remain valid.
3. Refund of contract performance bond:% of the performance bond will be refunded after the project starts, and% of the performance bond will be refunded when the completion acceptance conditions are met.
Article 9 Payment Terms
1. Party B shall pay% of the completed works to Party B within 15 days after Party A verifies and confirms the works.
2, after the acceptance of the project, pay% of the total project cost.
3. After the project is completed and accepted, Party B shall assign qualified full-time engineering accountants to actively cooperate with the audit settlement. The settlement time is 2 months. The project settlement audit will be completed within 2 months. After the completion data is handed over to Party A for acceptance, it shall be paid to% of the final accounts of the project; Pay% of the final accounts of the project after filing is completed.
4. The% of the remaining project payment is the warranty payment, which shall be paid according to the warranty agreement between the two parties until all the project price is settled.
Article 10 Quality Assurance
If there are quality problems during the warranty period and Party B fails to carry out maintenance within 48 hours after receiving the notice from Party A, Party A has the right to arrange others to carry out maintenance, and the expenses incurred shall be deducted from the quality warranty fund, and the insufficient part shall be made up by Party B..
Article 11 Liability for breach of contract
1. After the agreement comes into effect, if one party fails to perform the agreement or unilaterally terminates the agreement, or unilaterally causes the other party to terminate the agreement, it shall bear the liquidated damages of% of the total project cost.
2. If Party B fails to complete the project and deliver the project on time according to the agreed completion date, Party B shall pay liquidated damages of RMB/day to Party A, and Party A shall pay bonus of RMB to Party B every day in advance.
3. Party B shall provide complete completion data within 20 days from the date of completion acceptance; Party A shall pay a penalty of RMB/day to Party A for overdue submission, and Party A shall pay a bonus of RMB/day to Party B every day in advance.
Article 12 Others
1. Before commencement, both parties shall sign a steel structure construction contract.
2. Party B is responsible for cleaning up the construction waste and domestic waste generated by the construction on time.
3. All clauses in this agreement are the contents of the contract and are included in the contract management. If there is any conflict between the terms of this agreement and the big contract, the terms of this agreement shall prevail.
4. This agreement has the same legal effect as the construction contract.
5. This agreement is made in quadruplicate, and each party holds two copies. It will take effect after being signed and sealed by both parties, and will automatically become invalid after the project payment is paid.
6. In case of any dispute, both parties shall settle it through friendly negotiation. If negotiation fails, a lawsuit shall be brought to the local arbitration commission or the people's court where the construction is located.
Party A:
Party B:
date month year
Five simple engineering construction contracts.
Party A:
Party B:
Party A is located in a private residence, and the construction is contracted by Party B. In order to ensure the interests of both parties and fulfill their commitments and obligations, Party A and Party B have reached the following agreement through consultation:
I. Scope of Construction
Except the foundation, Party B shall be responsible for the construction of all the houses on the first floor to the fourth floor of Party A (including the production of steel bars, stairs, fences, water and electricity, and the decoration of front and rear external walls), and the interior of the houses shall be built to the rough wall and the ground.
Second, the construction mode
Party A is responsible for providing materials needed for construction, and Party B is responsible for providing equipment, tools, appliances and safety facilities needed for construction according to the construction drawings provided by Party A. ..
Third, the contract price
According to the construction area 1 10 yuan/m2, with a total area of about 480m2 and a total investment of 500,000 yuan (including materials), the actual construction area of the house undertaken by Party B is finally determined. ..
Four. mode of payment
By installment, Party B will complete the first floor construction, and Party A will pay 10000 yuan after it is qualified. The second floor to the fourth floor shall also be paid, and the balance shall be paid in one lump sum after Party A's acceptance.
Verb (abbreviation for verb) rights and obligations
(1) obligation
1. Party A must provide materials needed for construction according to the construction progress; Party A shall bear the losses caused by the shortage of materials.
2. Party A must pay the construction project funds according to the time agreed in the contract;
3. Party B must complete the housing construction task according to the housing construction quality standards and Party A's requirements; If rework is caused by Party B, all losses shall be borne by Party B. ..
4. For building materials, Party B shall notify Party A to prepare them two days in advance.
5. Party B must properly manage the materials provided by Party A to avoid loss and waste.
(2) Rights
1. Party A has the right to check the quality of the project. If the quality is unqualified, Party A has the right to request rework.
2. Party B has the right to ask Party A to pay the project payment according to the time agreed in the contract.
Sixth, the security protocol.
The unit price agreed in this contract has included the safety construction fee, so Party B must take safety measures at the construction site, educate the workers on safety and ensure the safe operation during the construction. Any safety accidents in the construction process shall be borne by Party B. ..
Seven. responsibility for breach of contract
If either party breaches the contract, it shall bear 65,438+00% of the total project cost of Party B. If any party breaches the contract seriously and causes heavy losses, it must pay compensation according to the price.
Eight. In case of any contract dispute, Party A and Party B shall settle it through friendly negotiation. If negotiation fails, both parties may bring a lawsuit to the people's court.
Nine. For matters not covered, Party A and Party B may separately agree as an annex to this contract, which has the same effect as this contract.
X this contract shall come into effect after being signed and sealed by both parties. If the house construction is qualified, it will automatically become invalid after the project payment is paid in full.
XI。 This contract is made in duplicate, one for each party.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Three articles related to simple engineering construction contract template;
★ 3 Simple engineering construction contract template
★ 3 Simple template for construction contract.
★ 3 copies of simple project contract
★ 3 samples of simple project contract
★ 3 simple engineering contract models are the latest.
★ 3 copies of the latest template of simple construction contract.
★ 3. Simple version of the project contracting agreement.
★ Latest contracts for 3 simple projects
★ 3 Simple contract for construction project contracting
★ 3 Simple project contracting agreement
var _ HMT = _ HMT | |[]； (function(){ var hm = document . createelement(" script ")； hm.src = "/hm.js？ fff 14745 ACA 9358 ff 875 ff 9 ACA 1296 B3 "； var s = document . getelementsbytagname(" script ")[0]； s.parentNode.insertBefore(hm，s)； })();