Construction Contract for Door and Window Curtain Wall 1
Employer:
Contractor:
In accordance with the Contract Law, Regulations on Construction and Installation Contracts and relevant regulations, and in order to clarify the rights, obligations and economic responsibilities of both parties in the construction process, this contract is signed by both parties through consultation.
Article 1 General situation of the project
I. Project name:
Second, the project site selection:
Three. Scope and content of the contract: processing of concealed curtain wall frames (unit price 35 yuan/unit).
Fourth, the contracting method: the contractor does not include materials. The contractor shall bear the cost of labor tools, machines and tools, labor insurance supplies, etc.
Verb (abbreviation of verb) quality grade: qualified.
6. Processing capacity: (tentative) 2,500 pieces, contract price: (tentative) 87,500 yuan.
Seven, the actual payment amount is calculated and determined according to the processing capacity recognized by both parties.
Article 2 Time limit for processing
1. Start date: YY.
Time limit for completion: year month day.
Total calendar duration: days.
Second, the processing sequence and operation arrangement of curtain wall window can be arranged according to the owner's requirements.
Article 3 Processing quality
A, the contractor must be in strict accordance with the technical documents provided by the employer, including drawings, processing process sheets and curtain wall engineering construction specifications and quality standards promulgated by the state for processing.
2. The contractor accepts the management and supervision of the site representative of the Employer; Homework arrangement.
Third, the appearance quality and machining accuracy are qualified. Meet the corresponding appearance quality inspection standards.
Four. Both parties shall abide by the following provisions:
1. The owner shall provide all materials needed for processing window sash, including window profiles, auxiliary materials and hardware. The quantity and variety of materials must meet the requirements of quantity and quality of window sash.
Verb (abbreviation of verb) supplementary clause (1):
Supplementary clauses of intransitive verbs (2);
Article 4 Payment Terms
1. After the contract comes into effect, the employer shall pay the contract amount according to the actual delivery quantity, that is, the processing unit price multiplied by the delivery quantity.
Second, the employer will take delivery of the goods at one time according to the verified processing capacity.
Article 5 The work of the employer:
1. Provide all raw materials for processing, including window profiles, hardware and accessories.
2. Provide complete technical data within 2 days after signing the contract, including necessary processing drawings, processing sheets and other necessary technical documents.
3. Regularly extract processed products.
Article 6 Work of the Contractor:
1. Process products according to the employer's processing drawings and process drawings. The contents include: cutting and framing of window sash, and hinge support (two pairs per pair)/each. Installation of handle and its accessories.
2. Be responsible for regularly and quantitatively completing the processing tasks according to the processing plan provided by the employer.
3, responsible for delivery (finished products) handover, inventory.
4. The remaining materials (300mm) of the processing plant shall be owned by the contractor.
5. The employer shall allow the contractor to have a tolerance rate of 5‰, that is, the raw materials are damaged due to uncontrollable reasons during processing.
6. Be responsible for transporting the curtain wall window profiles to the contractor's processing site, and returning the later products, that is, bear the transportation expenses.
Article 7 Liability of both parties
In addition to implementing the provisions of the contract, the contractor shall also bear the following responsibilities:
I. Employer's Responsibility
1. Pay in time according to the payment terms stipulated in the contract.
2. Check the quality of the processed products, and sign for them if they are qualified.
3. Fulfill the contents specified in Article 5 of this contract.
4. If the goods are not delivered on time, resulting in a backlog of products, which exceeds the time limit stipulated in the contract, the employer shall pay the corresponding storage fee, calculated at (1 yuan)/day.
Second, the contractor's responsibility
1. After signing the contract and receiving the technical documents required for processing, start the processing operation.
2. Complete the processing tasks of the Employer on a regular basis, and bear all consequences caused by unfavorable processing.
3. The contractor shall not subcontract the contract separately. Otherwise, the employer has the right to terminate the contract and require the contractor to bear the economic compensation liability.
Article 8 Liability for breach of contract
1. Either party's failure to fully perform the terms of the contract is a breach of contract. The legal liability and economic liability caused by breach of contract shall be borne and compensated by the breaching party.
2. If the contract is broken halfway without justifiable reasons, the breaching party shall bear legal responsibilities. In addition to compensating the observant party for all economic losses, it shall also pay the observant party a fine of 30% of the contract amount.
Article 9 Contract disputes
Disputes arising from the execution of this contract shall be settled by both parties through consultation. If negotiation fails, both parties agree to arbitrate by Tangshan Arbitration Commission. If no arbitration agreement is reached, a lawsuit may be brought to the people's court where the contract is signed.
Article 10 Termination of the Contract
If the performance of this contract cannot be continued due to policy changes, force majeure factors and reasons other than those of both parties, both parties may terminate this contract through consultation and handle settlement matters.
Article 11 Supplementary Provisions
1. This contract is made in duplicate, and its annexes are made in duplicate, with each party holding one copy. If notarization is needed, it shall be sent to the notary department of the place where the contract is signed for notarization.
2. This contract shall come into effect after being signed and stamped by the representatives of both parties; If notarization is needed, it will take effect from the date of completion of notarization.
Three, after the signing of the contract, if both parties need to make amendments, the two sides can sign a supplementary agreement, which has the same legal effect as the main contract.
Four. Matters not covered in this contract shall be implemented in accordance with People's Republic of China (PRC) Contract Law and relevant laws and regulations.
Employer: Contractor:
Legal representative (signature): Legal representative (signature):
Authorized Agent (Signature): Authorized Agent (Signature): Company Address: Company Address:
Tel: Tel:
Bank of deposit: Bank of deposit:
Account number: Account number:
Contract signing place:
Date of signing the contract: year month day.
Windows and doors curtain wall construction contract 2
(hereinafter referred to as Party A)
Employer: (hereinafter referred to as Party B)
Through friendly negotiation between both parties, Party B is entrusted to construct aluminum alloy doors and windows and glass curtain wall project of villa building. In order to clarify the rights and obligations of both parties, this contract is formulated in accordance with the Contract Law of People's Republic of China (PRC), Regulations on Construction and Installation Project Contracting and other relevant laws and regulations, and both parties shall abide by it and strictly implement it.
1. Project content: aluminum alloy doors and windows of villa building, glass curtain wall and some aluminum alloy doors and windows of main building.
Second, the way of contracting: contracting for labor and materials.
3. Project Location: East of South Ring Road
Four. Time limit for a project: the construction conditions are met from the date of signing the contract, and it will be completed within 30 days after both parties sign the contract.
Five, the quality standard requirements:
(1), the content requirements all meet the evaluation standards of excellent projects in Shandong Province;
(2) In order to coordinate the whole project and facilitate the construction acceptance, Party B must provide intermediate materials and acceptance materials in time;
(3) If the project undertaken by Party B fails to meet the local excellent quality standards through quality supervision and quality evaluation by the construction engineering department, 5% of the total contract price will be deducted when the project is settled;
(4) In this project, if the quality of aluminum alloy doors, windows and glass curtain walls can not meet the excellent standard, the construction unit shall bear the responsibility;
Contract cost of intransitive verbs: The total cost of this project is tentatively set at 200,000 yuan (two hundred thousand yuan only). According to the actual installation area (the actual area shall be subject to the outside of the door frame, not to the hole).
Seven, engineering requirements:
1. Scope of construction: the in-depth design and construction of aluminum alloy doors and windows in villa buildings, glass curtain walls and some aluminum alloy doors and windows in the main building, including the transportation, construction and installation, completion acceptance and after-sales service of materials and components used in the project.
2. Basic requirements for aluminum alloy doors and windows of villa buildings and main buildings:
A, aluminum alloy profile adopts Nanshan electrophoretic paint profile, and the color is big champagne.
B, the glass is Zibo Jinjing or Qinhuangdao Hua Yao, the glass is float toughened glass, the door glass is 6㎜ thick, the window glass is 6+9A+6 thick hollow toughened glass, the inside glass is transparent, and the outside glass is French green.
C, door locks and doors and windows hardware using Li Xing or Liang Jian products. The door lock is a 4-point lock. The handle inside the door lock is movable and the handle outside is fixed. No key and lock tongue are needed, and the color is the same as that of aluminum alloy profile.
D, doors and windows glass with glass glue seal.
E, all doors and windows are changed to plane doors and windows, and meet the requirements of drawings and the relevant provisions of relevant national codes.
3, glass curtain wall basic requirements:
A, glass curtain wall adopts open frame curtain wall, curtain wall frame as shown in the drawings;
B. Tempered glass is made of Qinhuangdao Hua Yao or Zibo Gold Crystal, and the color of glass curtain wall is French green;
C, the aluminum profile is selected from Shandong aluminum industrial profile;
D, the surface treatment of the whole piece of aluminum is electrophoretic coating, the color is champagne, and the coating thickness should meet the design and specification requirements;
E, open frame curtain wall profile, cross keel and vertical keel section size and wall thickness are designed according to the principle of equal pressure, and the section size is determined by calculation. However, the open frame curtain wall must meet the following requirements: the outdoor horizontal frame and vertical frame are buckled, and the side width is 80 mm
F. Selection of structural sealant and weatherproof sealant (Guangzhou Baiyun, Zhengzhou Zhongyuan and Hangzhou Zhijiang).
G, auxiliary materials used in curtain wall, must comply with the specifications and design requirements.
H. Party B shall provide detailed drawings of curtain wall embedded parts; Plan, elevation and node details; Design basis and related calculations, selection of materials used and other explanations to be submitted. (Test report, product certificate, certificate, and materials that need to be rechecked should be rechecked).
I, glass curtain wall is fully enclosed, and meet the relevant provisions of the drawings and national standards.
Eight. terms of payment
When signing the contract, personnel, machinery and finished materials will enter the site and complete half of the engineering quantity, and pay 30% of the contract price for the project; Pay 80% of the contract price after the completion of the project; Pay 90% of the contract price after the completion of project acceptance settlement; The remaining 10% is used as the project quality deposit, which will be settled within one year from the date of project acceptance (interest-free). Construction water and electricity are purchased from Party A by the construction unit, and the electricity price is 1 yuan /kWh. The water price is in 2.5 yuan/Fang.
Nine, material comprehensive unit price:
The comprehensive unit price will not be adjusted during the construction period.
X. Project warranty
(1) When the project is settled, 10% of the total settlement amount is reserved as the project quality warranty fund.
(2) After the project is completed and accepted, within the warranty period stipulated in the contract, if Party A finds that the project within the scope stipulated in the contract is defective or has construction quality problems, it may require the contractor to repair it immediately. The contractor must send professionals to the site for repair within 7 days after receiving the notice from the bid issuing unit, and send professionals to the site for repair within 1 day for construction quality problems that affect production. Otherwise, the limited company can organize maintenance by itself, and the resulting cost 1 will be directly deducted from the reserved quality warranty.
Xi。 Safety requirements: During the construction, if Party A's equipment and materials are damaged due to Party B's reasons, Party B shall compensate all losses. Strengthen the safety education for Party B's construction personnel, and Party B shall take full responsibility for personal and equipment safety accidents during construction.
12. Project management, technical service, project management, liquidated damages and other agreements: refer to similar matters in aluminum alloy doors and windows and glass curtain wall projects signed on February 8, 2006 for project management, technical service, project management, liquidated damages, open-frame glass and aluminum alloy doors and windows processing drawings and other agreements.
Thirteen. This contract is made in sextuplicate, four for Party A and two for Party B, and shall be implemented as of the date of signing.
Party A: (official seal) address, legal representative, entrusted representative, telegram and fax:
Party B: (official seal) address, legal representative, authorized representative, telegram and fax:
Year month day:
Construction Contract for Door, Window and Curtain Wall 3
Entrusting unit: hereinafter referred to as (Party A)
Design unit: hereinafter referred to as (Party B)
Agent: hereinafter referred to as (Party C)
In accordance with the relevant provisions of the Regulations on the Administration of Survey and Design of Construction Projects, relevant national codes and standards, and in view of the fact that Party B's qualification grade conforms to the national regulations, it can undertake the engineering design business of building curtain wall (Longwan Construction Building) invested by Party A, and both parties agree to sign this contract through friendly negotiation for mutual compliance.
I. Overview of the Project
1. 1 name of construction unit:
1.2 project name:
1.3 design and survey of internal pole, cornice, cornice ceiling, floor spring door and structural embedded parts.
1.4 quantity (㎡) (quantity shall be settled according to actual development area)
Second, the design basis
2. 1 Architectural design drawings provided by the owner
2.2 The main technical standards adopted by the designer are relevant national, local and industrial codes and relevant design requirements of the owner, including but not limited to the following contents:
① Design Standard for Energy Efficiency of Public Buildings (GB50 189-20_)
② Building curtain wall (GB/T2 1086-20_)
③ Technical Code for Glass Curtain Wall Engineering (JGJ 102-20_)
④ Technical Specification for Metal and Stone Curtain Wall Engineering (JGJ 135-20_)
⑤ Code for Quality Acceptance of Building Decoration Engineering (GB502 10-20_)
⑥ Limit of harmful substances in adhesive (GB 18583-20_)
⑦ Code for Fire Protection Design of High-rise Civil Buildings
If the above standards are updated, the latest standards shall prevail.
Three. Obligations of Party A
3. 1 Provide engineering electronic layout (construction drawing, structural drawing, node details)
3.2 Before the project starts, Party A shall organize the construction unit to carry out design technical disclosure with Party B. ..
3.3 Handle "filing" and other related legal affairs.
Four. Obligations of Party B
4. 1 Party B must carry out the design according to the national mandatory standards for engineering construction and the requirements for the design depth of the construction project specified by the state, and deliver the construction design scheme documents to Party A before (effect drawing, general design description, elevation drawing, plan drawing, section drawing, stone partition drawing, door and window detail drawing, section detail drawing, lightning protection connection drawing, embedded part drawing, detail drawing, standard node drawing, etc.). ); After the scheme diagram is determined, the design time of the construction drawing is 25 working days, of which the design documents are in duplicate and the electronic version is provided. If drawing text is added, the cost will be calculated separately.
4.2 Party B is responsible for the drawing reply of the drawing review center.
4.3 Contact the architectural design institute, do a good job in external thermal insulation and energy-saving design, solicit opinions from the construction unit in time, and modify relevant design opinions of the design institute in time.
4.4 Designers should complete the following tasks.
A, participate in the verification and communication between the entrusting unit and the architectural design institute.
B, explain the construction technology.
C, timely design disclosure to the construction unit, deal with relevant design issues, participate in the completion inspection and acceptance work, and put forward opinions.
Five, the design fee payment method
5. 1 The design fee of this project is calculated in RMB per square meter, and the total design fee is RMB (in words:
5.2 After signing the contract, Party A shall pay the design fee of RMB Yuan only within three days, enter the construction drawing design after the construction design scheme is determined, and pay all the design fees within one week after the construction drawing review is completed.
Liability for breach of contract of intransitive verbs
6. 1 If Party A fails to pay the design fee to Party B on time as stipulated in the contract, it shall pay liquidated damages to Party B as stipulated by the bank on deferred payment.
6.2 Design omissions or errors shall be revised and supplemented in time. (Compensation for wrong losses shall be made according to national standards and terms. )
6.3 If Party A and Party B request to terminate the contract midway, they shall compensate (both parties are equal).
Seven. others
7. 1 If the project designed by Party B wins the bid, Party B will not charge any design fee as a discount.
7.2 This contract shall come into effect as of the date when Party A pays the first design fee. If there are any matters not covered in this contract, both parties shall negotiate together. If there is a supplementary agreement, the supplementary agreement shall have the same effect as this contract.
7.3 The design service life of curtain wall in this project is 20_ years.
7.4 Matters not covered in this contract shall be handled in accordance with relevant laws and regulations of China.
7.5 Any dispute shall be under the jurisdiction of the people's court where the project is located.
This Agreement is made in sextuplicate, with Party A, Party B and Party C holding two copies respectively.
Entrusting unit (Party A)
Design unit (Party B)
Agent (Party C)
date month year
Relevant clauses of Simple Contract 3 for Construction of Door, Window and Curtain Wall:
★ 3 simple demonstration contracts for door and window engineering.
Taken the door and window engineering contract template 3 concise version.
★ 3 concise versions of the model contract for doors and windows in 2020.
★ There are 3 simple model contracts for doors and windows.
★ 3 model articles for door and window engineering contract.
★ 3 copies of model contract for door and window engineering.
★ Three contracts for aluminum alloy doors and windows engineering.
★ The latest model of door and window engineering contract.
★ The latest model of classic door and window engineering contract.
★ There are three simple contracts for plastic steel windows.