Model contract for interior and exterior wall coatings 1
Employer: (hereinafter referred to as Party A) Contractor: (hereinafter referred to as Party B)
Party A subcontracts the indoor putty, external wall insulation and coating sub-projects of G 1# residential building in Jinlu Bole City to Party B for construction. In order to ensure safe production and civilized construction, and ensure the smooth progress of the project quality and time limit for a project, both parties, based on the principles of equality, honesty and mutual benefit, have better defined their respective responsibilities, rights and interests, and reached the following agreement through friendly negotiation:
I. Overview of signing the contract:
1 coating component project
2. Form of contract: The contractor's packaging has passed the inspection.
Second, the scope of contracting:
Indoor putty, external wall insulation and coating for G 1# residential building in Jinlu Bole City.
Third, the contract unit price:
1. Indoor putty: cement gypsum primer brush, cement gypsum mortar plastering, barbed wire hanging at the junction, water-resistant flexible putty scraping twice; Unit price 30 yuan/m2. (RMB thirty yuan per square meter only) calculated according to the construction area.
2. External wall insulation: 90-thick polystyrene board insulation, bulk density 20kg/m3, fire resistance grade B 1, 20-thick polymer anti-crack mortar (pressed into alkali-resistant glass fiber grid cloth); Unit price 68 yuan/m2. (Sixty-eight Yuan per square meter only) Calculated according to the actual area.
3. Exterior wall coating: one coat and two coats of high-elastic acrylic coating; Unit price 18 yuan/m2. (RMB 180 per square meter) Calculated according to the actual area.
Four. Payment method:
Pay according to the construction progress, and the roof project fee, the house is the second to fifth floors of the multi-storey residential building in the construction community, ranging from 3,900 yuan to 4,200 yuan /m2.
Five, the time limit for a project requirements:
Duration: The completion date of the project is September 65438, 2005.
If the construction period is delayed due to Party B's reasons, it will be fined 1000 yuan for each day of delay.
Note: The construction period can be postponed in the following circumstances: a. Open-air construction, postponed in case of rain; B, the civil contractor can't submit the base surface that meets the waterproof requirements in time; C. Party A fails to pay in time as stipulated in the contract; D, engineering design changes; E, cross construction operation influence; F other circumstances agreed in the contract or agreed by the civil representative.
Six, quality requirements:
1, the project should be organized according to the requirements of drawings, design, construction specifications and relevant technical standards, and must meet the requirements specified in the specifications. The quality of the project must meet the qualified standards. After being accepted by the quality supervision and management department of the local government according to the current national norms and acceptance evaluation standards, if the quality is unqualified, Party B shall unconditionally repair it until it is qualified, and Party B shall bear the compensation for the economic losses and delays caused thereby. Those who fail the final inspection will not be settled.
2. This project implements the quality reward and punishment system, and Party B will be fined 100 yuan for each quality problem found.
Seven. Responsibilities of both parties:
Party A's responsibilities:
1. Provide Party B with on-site materials stacking place, water and electricity supply, etc. Free of charge;
2. Responsible for project team coordination;
3. Supervise Party B's construction quality, construction progress and construction safety, and assist Party B in finished product protection;
4. If the drawings or site size changes, items are added or deleted, Party B shall be informed in time; Party B's responsibilities:
1. Party B's construction must meet relevant safety requirements (1). Party B's personnel shall carry out construction in strict accordance with the provisions of waterproof construction specifications, and be equipped with full-time technical personnel; (2) Party B shall abide by the laws and regulations on production safety; (3) Obey the unified coordination and management of work safety; (4) Party B shall prepare safety technical measures or plans within the scope of the contract (5) Party B shall seriously implement safety technical measures or plans, establish and improve the responsibility system for production safety, improve production conditions and ensure production safety; (6) Party B shall carry out the construction in strict accordance with the relevant national, provincial and municipal safety production operation norms and procedures. In case of any safety accident during the construction period, all economic losses and legal responsibilities shall be borne by Party B, which has nothing to do with Party A.. ..
2. Carefully construct in strict accordance with the design drawings and the requirements of the project department, and complete the task on time with good quality and quantity. Common quality defects and problems must be eliminated during the operation, and Party B shall bear its economic losses for the quality problems caused by Party B's responsibility.
3. After the project is completed, Party B shall be responsible for providing the quality inspection report and retest report issued by the relevant state departments.
4, responsible for the team mount guard personnel quality, safety technical disclosure, quality, safety acceptance quality standard disclosure; Conduct pre-job safety education.
5. If Party B causes damage to Party A or a third party during the construction, it shall be liable for compensation.
6. While doing a good job in protecting the finished products of this specialty, Party B should take measures to prevent fire pollution or damage the finished products and semi-finished products of other specialties, and be responsible for cleaning up the pollution caused by construction projects within the contracted scope in time.
7. Party B shall not subcontract this sub-project by itself. If Party A is found to have the right to terminate this agreement and subcontract the construction to other units, Party B shall be responsible for compensating the economic losses caused thereby.
Eight, safe production and civilized construction:
1. After entering the site, Party B must strictly abide by the relevant requirements of the Regulations on the Administration of Work Safety in Construction Projects and consciously abide by Party A's safety supervision and various rules and regulations. In the process of construction, it must be carried out in strict accordance with the safety operation specifications. If Party B fails to carry out the construction according to the regulations, all accidents due to work, injury, disability and death shall be borne by Party B..
2. Party B's personnel must wear safety helmets correctly when entering the construction site, and must wear safety belts when working at height. If it is found that Party B's personnel do not wear safety helmets and safety belts according to relevant regulations when entering the construction site, and there are no safety protection measures, everyone will be punished according to 50 yuan.
3. Temporary water and electricity use for construction must be set and connected by professionals. It is strictly forbidden to pull and build without permission, and it is strictly forbidden to use the "three stoves" and other electrical appliances that cannot be used in the construction site. If cooking and boiling water are found, all the electrical appliances used will be confiscated, and each person will be fined 200 yuan.
4. During the construction, Party B shall closely cooperate with the team and management departments at all levels, obey the unified command and arrangement, and it is forbidden to fight and gamble at the construction site, and it is forbidden to go to work after drinking. The violator will be fined 1000 yuan each time, which will be deducted from the salary and accepted by Party B unconditionally.
5. Safety Responsibility According to the relevant spirit, the principle of who is responsible for construction and who is responsible for safety is implemented. Party B must pay the security protection fee. In case of safety problems, all legal responsibilities and economic expenses shall be borne by Party B. ..
6. Party B must do a good job in the environmental sanitation of the construction site.
7. All kinds of mechanical equipment, safety management, protective facilities, warnings and safety signs shall not be removed and moved at will.
8. In order to ensure the safe and civilized construction on site, Party B must keep his hands clean, and it is forbidden to throw things about. Otherwise, 500 yuan will be fined every time.
9. Party B is responsible for cleaning the ground after each working procedure is completed, and keeping the ground clean before civilized construction and acceptance.
10, consciously obey the management of Party A, strengthen the management of its own team at the same time, and closely cooperate with Party A to manage civilized construction.
Nine. Warranty measures:
After the project is completed, Party B's free warranty period is one year. In case of quality problems during the warranty period, Party B shall guarantee them free of charge. Party A shall notify Party B according to this contract, and Party B shall immediately organize manpower and material resources to rush to the site for maintenance after receiving the warranty notice, and Party B shall not shirk it for any reason.
X. Supplementary provisions:
1. Matters not covered in this agreement shall be settled by both parties through friendly negotiation based on the principle of seeking truth from facts. If negotiation fails, either party may apply to the local arbitration commission for arbitration. The arbitration result is final and both parties must abide by it unconditionally.
2. This agreement shall come into force as of the date of signing, and shall automatically become invalid after the completion payment of the project is paid. This agreement is made in duplicate, one for each party.
Signature of Party A:
Date of signing:
Signature of Party B:
Model contract for interior and exterior wall coatings II
Party A: (hereinafter referred to as Party A)
Party B: (hereinafter referred to as Party B)
Now Party A intends to contract out the interior decoration project of Xiangqiao Jiayuan Project to Party B. In order to clarify the obligations and responsibilities of both parties, both parties sign this contract on the principle of fairness, justice, honesty and credit through consultation.
What is stated in this contract is the result of agreement between both parties, and the agreed rights and obligations are the guidelines that both parties should abide by. If either party breaches the contract or damages the legitimate interests of the other party, the other party has the right to investigate its liability for breach of contract according to law. The specific contract terms are as follows:
1. Project name: Xiangqiao Jiayuan Community 1#~3# Building and Basement.
2. Project Location: Huanghe Village, Yuelu District, Changsha City
Three. Scope of Contract: Construction
Paint and paint decoration works shall be subject to the quantities stated in the construction drawing of Xiangqiao Jiayuan provided by Party A, including the labor and material costs incurred in transportation, stacking, cleaning, maintenance and civilized construction measures on the construction site. The specific contracting scope is as follows:
65438+
2, indoor halls, rooms, corridors, indoor gardens and other ceiling brush cement mortar.
3, balcony ceiling and beam brush exterior wall waterproof white latex coating.
4. The elevator front room, ceiling, public corridor and ceiling are painted with white latex paint.
5, stair wall, ceiling interior wall brush white latex paint.
6, stair rest platform, step brush dark gray 505 latex paint.
7, the basement wall, ceiling brush 888 imitation enamel.
8. Cooperate with the project department and superior leaders to conduct on-site inspection of all labor forces and bear labor costs.
9. Party A shall be responsible for providing natural cement.
All the above procedures, including surface deslagging, joint planing and leveling, steel bar head and nail cleaning, full putty scraping, internal and external corner trimming, sandpaper grinding, scaffolding for construction, repair, finished product protection and sanitation work, are within the scope of this contract.
Four, the contracting method and time limit for a project:
1, contractor, contractor, contractor, contractor, contractor, contractor, contractor, contractor, contractor, contractor, contractor, contractor, contractor, contractor, contractor, contractor, contractor.
2. Time limit: it must be completed within days from the date of entry, and the delay time limit is within 7 days. From the eighth day of the delay in the construction period, a fine of 5,000 yuan/day will be imposed for each day of delay until the project is completed. If the project is completed ahead of schedule, it will not be rewarded within 7 days. If it exceeds 7 days, the reward of 5,000 yuan/day will be calculated from the eighth day in advance (considering the construction quality and construction input cost, it is not recommended to advance 65,438+. )
3. Within the scope of the contract, Party A is responsible for the required power tools, cables, lighting lamps, etc. Party A only provides the floor power switch box.
Verb (abbreviation of verb) Contract unit price and settlement method:
1. The total price and unit price of this project shall include but not limited to the following contents:
1.65438+
1.2. The unit price includes all expenses such as labor wages, auxiliary materials, temporary lighting (except vertical transportation machinery), management fees and profits, as well as market risks and all expenses invested by Party B to realize the construction period, safe and civilized construction and quality level agreed in the contract after fully understanding the site conditions of this project. Under no circumstances shall we propose to adjust the contract unit price.
2, physical quantity contract unit price details:
2. 1, the external wall shall be brushed with drip line, the bottom of the gutter, the sloping roof, the roof parapet, the roof truss and the balcony drip line. Smoke hood, elevator machine room, air conditioning board bottom, surface, window top line, etc. All of them are waterproof white latex coatings for external walls /m2. (Calculated by construction area)
2.2, indoor hall, room, corridor, indoor garden ceiling brush cement mortar yuan /m2 (according to the actual area).
2.3, balcony ceiling and beam brush waterproof white latex paint yuan /m2. (Calculated by actual area)
2.4. White latex coating for elevator foreroom, ceiling, public corridor, ceiling and interior wall is RMB /m2. (Calculated by actual area)
2.5, stair metope, ceiling brush indoor white latex paint yuan /m2. (Calculated by actual area)
2.6, stair rest platform, step brush dark gray 505 latex paint yuan /m2. (Calculated by projected area)
2.7, basement exterior wall, ceiling brush 888 fangci paint yuan /m2. (Calculated by actual area)
3, project settlement:
3. 1. Settlement method: this project adopts the lump sum method of physical quantity and unit price.
3.2. Settlement method: approved engineering quantity × fixed total price, comprehensive unit price+engineering change negotiation-liquidated damages, etc.
3.3, on-site economic visa must be approved by the project budget, the builder. Only three chief engineers * * * sign together to take effect.
3.4. Party B shall submit the settlement data in triplicate within 20 days after the completion of all the projects undertaken. Settlement submitted by Party B (including engineering quantity calculation formula and relevant on-site economic visa, etc.). It will take effect after being approved by the project leader, otherwise it will be invalid, and one copy will be returned to Party B after the settlement takes effect.
Terms of payment for intransitive verbs:
1. Down payment: 70% of the external wall project is completed, and 70% of the contract unit price shall be paid according to the actual completed qualified project.
2. Second payment: When the outer frame is dismantled, 70% of the contract unit price shall be paid according to the actually completed qualified quantities.
3. The third payment: the outer frame is completely dismantled, and 80% of the contract unit price is paid according to the actually completed qualified quantities.
4. The fourth payment: 95% of the total actual project price shall be paid after the completion acceptance (5% of the total project price shall be reserved as a quality deposit, which shall be fully returned to Party B within three months after the expiration of the warranty period 1 year. If there is any quality problem, Party A will directly deduct relevant expenses until the deduction is completed).
Seven, safety management and civilized construction:
(A) safety management
1. Party B has the right to reject the accusation that Party A violates the safety regulations.
2. The person who signed the contract is the first responsible person, and has the responsibility to take all positive safety measures, organize safety production, and go deep into the construction site to grasp safety management.
3. Safety indicators: zero death, zero serious injury, and the general safety accidents are minimized.
4.( 1) Party B shall strictly abide by the operating rules and shall not operate illegally. In case of safety accident, all responsibilities and expenses shall be borne by Party B. ..
(2) If the safety accidents of other teams are caused by this team, the project department will coordinate and all expenses will be borne by the responsible team.
5, abide by the safety system and safety measures of the site, the person in charge must stick to the construction site 24 hours a day, to assist in project management. In special circumstances, it is necessary to ask for leave from the project department for approval, and each time you leave without reason, you will be fined 1000 yuan.
(2) Civilized construction
1. Operators must wear safety helmets when entering the construction site; Dress clean.
2. After the operation, stop the power-off machine and isolate the personnel, clean up the Chinese food before dinner, and pile up the remaining materials for reuse. Otherwise, 200 yuan will be fined every time and ordered to make corrections. Those who do not correct will be fined twice.
3. civilized construction measures: 65,438+0% of contract price. If Party B fails to meet the provincial civilized construction site standards, Party A has the right to directly deduct it from the project payment.
4. Fighting or gathering people to make trouble is prohibited, otherwise, a fine of 20_ yuan will be imposed.
5. Within the scope of the construction site, it is not allowed to open a new stove, and you can only eat in the canteen. The contractor shall not take children to live on the site, otherwise 200 yuan will be fined every time.
6. Party B's materials shall be stacked in an orderly manner according to different specifications, and the site shall be kept clean at all times, free of loose ash and accumulated water, and the equipment shall be kept clean at all times during transportation, otherwise, 200 yuan shall be fined every time and corrected immediately, and the penalty shall be doubled if it is not corrected.
7. Strictly abide by Party A's rules and regulations, otherwise, Party A has the right to terminate Party B's contract, and Party B shall bear the losses caused thereby.
Eight, the construction progress and construction quality:
1. Party B must obey the leadership and command of the project leader and chief engineer, and organize and coordinate the construction work according to the construction progress plan provided by the project department, otherwise it will be punished according to relevant systems.
2. Party B must carry out scientific management and reasonable construction to achieve rapid, economical, safe, civilized, continuous and orderly operation. 50% of the economic benefits generated by Party B's rationalization proposal being adopted by Party A can be rewarded.
3. Party B must cooperate closely with Party A to ensure the construction progress and total construction period of each node, and at the same time, it must cooperate with the fine decoration and landscape garden construction of the sales department of the developer and the model room, and cooperate with other subcontractors of the construction party, otherwise it will be punished according to the relevant system (see the construction progress reward and punishment system for details).
4. If Party B fails to reach the project schedule, Party A may arrange another construction team to complete part or all of the project contracted by Party B, and the expenses shall be borne by Party B. Party A may also directly terminate the contract, and the losses caused thereby shall be borne by Party B.. ..
(2) Construction quality
1, the project quality must meet the requirements of the current national construction and acceptance specifications, and the construction, supervision, acceptance and delivery standards of model houses approved by Party A, otherwise a fine of 5% of the contract price will be imposed.
2, strengthen the construction quality management, it is forbidden to empty drum, dry crack, peeling and other quality problems.
3, according to the specification construction, to ensure that the wall is bright and clean, smooth, uniform color, no peeling.
4. The paint brand used for the interior and exterior walls of this project must be China Resources brand or Nippon brand. (Other brands are not allowed)
Nine. Liability for breach of contract:
1. If Party B violates the above terms or fails to meet Party A's requirements in terms of schedule and quality, Party A has the right to change the construction team, and settle accounts according to 60% of the completed qualified quantities when leaving the site.
2. If Party B fails to complete the project on schedule, Party B will be fined 65,438+0,000 yuan for each day of delay.
3. If Party B has no obvious behavior fault, Party A has no right to terminate the normal performance of the contract, otherwise it shall bear the liability for breach of contract.
4. If either party breaches the contract and negotiation fails, it may apply to the arbitration commission in the place where the contract is signed for arbitration.
X. other matters:
Matters not covered in this contract shall be settled by both parties through consultation. In case of failure to reach an agreement or need to be revised during the performance of this contract, both parties shall negotiate to form a written supplementary agreement, which shall have the same effect as the contents of this contract after being signed by both parties.
This agreement is made in quadruplicate, with Party A and Party B holding two copies respectively, which have legal effect.
Signature of Party A: Seal Tel:
Signature of Party B: phone number with seal:
ID number:
Home address:
date month year
Model contract for interior and exterior wall coatings 3
Employer (full name): _ _ _ _ Co., Ltd. (Party A)
Contractor (full name): _ _ _ _ _ Business Department (Party B)
In accordance with the Contract Law of People's Republic of China (PRC), the Regulations on Construction and Installation Engineering Contracts and other relevant laws and administrative regulations, following the principles of equality, voluntariness, fairness, honesty and credit, and combining with the actual situation of this project, both parties have reached an agreement through consultation to sign this contract for mutual compliance.
I. Overview of the Project:
1, project name: _ _ This project 1 bid section.
2. Project Location: _ _ Development Zone
3. Employer: _ _ Construction Co., Ltd.
2. Category, name, specification, quantity and project price of engineering materials:
1. Name, brand, specification, quantity and unit price of the goods:
The unit price in the bill of quantities is the comprehensive lump sum price. The lump sum price shall include: production personnel expenses, materials, machinery, tools, transportation, installation, coordination period, quality, profit, insurance, taxes and fees, necessary overtime expenses, patent expenses, packaging, air transportation and local storage expenses, transportation expenses, all expenses arising from the delay in the arrival of equipment and materials at the construction site, and other shed cleaning fees charged by various countries.
2. After the project is completed, Party A, together with the supervision unit, will organize relevant units and personnel for acceptance. After the acceptance, both parties sign the completion acceptance documents and completion data, and hand over the project to Party A for management. The quality guarantee period is 2 years from the date of acceptance.
3. During the warranty period, Party B shall provide technical support and training free of charge, and bear all expenses such as maintenance and replacement caused by product quality problems; If it is man-made damage, there will be a charge.
4. Party B shall guarantee the timeliness of the warranty and respond in time after receiving the notice from Party A and the owner. The specific time is as follows:
5. After Party A and the owner notify, Party B shall respond immediately. If there are problems that cannot be solved by telephone, the neck dispatcher will arrive at the scene within 24 hours and complete the warranty and maintenance projects related to quality problems within 7 days from the date of arrival at the scene. Otherwise, it shall be deemed that Party A or the owner has agreed to handle it, and the expenses shall be deducted from the quality guarantee fund.
3. Settlement method:
1. Payment method
A. Advance payment: Party A shall pay Party B 5% of the total (provisional) payment within calendar days from the day after the signing of this contract, that is, 100000 yuan as the contract deposit. 70% of the cost of materials will be paid on site. After the installation is completed, Party A shall pay 65,438+00% of the total project cost within 3 calendar days, and 65,438+00% after the project is accepted.
B the quality guarantee deposit is the contract settlement amount.
2. Payment method of quality deposit: 3% for one year, 2% within 15 calendar days after two years, and the balance shall be paid by Party A to Party B. ..
IV. Construction Preparation and Obligations of Both Parties
(I) Work of Party A
1. Before the project construction, Party A shall provide Party B with the design documents or change documents related to the pile construction and the revised design drawings, and assist Party B in preparing the construction organization design and reviewing the drawings.
2. Party A shall organize all relevant construction units to conduct handover inspection of ground engineering, pipeline engineering and other related projects one day before construction.
3. Cooperate with Party B to manage and coordinate the construction site. Cross-construction and wet operation of other projects are strictly prohibited. Provide the construction conditions of three links and one leveling, and the power supply and warehouse space required for construction.
4. Being appointed as the representative of Party A, responsible for performing the contract, supervising and accepting the quality and progress of the project, and handling related matters such as changes, visas and payment of project funds.
(II) Work of Party B:
1. Prepare the construction organization design according to the design documents provided by Party A and the actual situation on site, and carry out the construction in strict accordance with the drawings after being approved by Party A. ..
2. Be responsible for the materials required for the construction scope and content agreed in the project contract, and provide complete technical data, product certificates, inspection reports, etc.
3. Complete and deliver in strict accordance with the contract.
4. Appoint as the representative of Party B to be responsible for the performance of the contract. Organize the construction according to the requirements, ensure the quality and quantity, complete the construction tasks on schedule, and solve all matters that Party B is responsible for.
5. The construction scheme provided by Party B shall include:
(1) Description and detailed drawings of construction procedures;
(2) technical quality, schedule guarantee measures and safety and civilized measures;
(3) Guarantee measures for finished product protection and other aspects that must be explained in relevant construction organization design. Party B's construction plans and construction progress plans at various stages shall meet the total construction period requirements of the General Contractor.
6. Strictly implement the construction site management regulations, so as not to disturb the people and pollute the environment.
5. Delivery time, delivery place, goods stacking, contact person and contact information
1. delivery time: the employer will fax the required quantity to the contractor in writing days in advance, and the contractor will arrange production.
2. Place of delivery:
3. On-site representatives of Party A: 4 on-site representatives of Party B.. Contact information of Party A's representative: contact information of Party B's representative: both parties shall exercise their rights and perform their obligations according to the contract.
5. Party A designates relevant units to provide Party B with vertical transportation of materials, and Party B is responsible for unloading, short barge in the field and stacking to the place designated by Party A and neatly stacking.
Acceptance and warranty of intransitive verbs
1. Both parties agree to check and accept the project quality at the following stages in the construction process:
(1) Pre-construction acceptance: Party B shall inspect the site.
(2) Material mobilization: after arriving at the site 1 day, Party A's representative, Party B's representative, project supervisor and decoration general contractor will check and accept the appearance quality of the goods;
Note: Party B shall notify Party A of the acceptance days in advance, and fill in the project acceptance form after passing the stage acceptance.
2. The product and installation quality shall conform to the standards listed in the product samples and specifications and have corresponding functions, and must conform to national and local product specifications, industrial quality and technical standards, as well as Party A's technical standards and acceptance standards. Before the completion acceptance, Party B shall provide relevant completion acceptance materials (such as product certificate, green material sign authorization certificate, etc.). ) Requirements of decoration general contractor for each bid section.
3. Party B shall promptly notify Party A to handle the acceptance procedures for concealed works and intermediate works. If Party A fails to attend the acceptance as scheduled, Party B shall organize personnel to conduct the acceptance, and Party A shall acknowledge it in writing. After the completion of the project, Party A shall notify Party B for acceptance, and Party B shall organize acceptance within days after receiving the acceptance notice and fill in the project acceptance form. Handle the handover procedures after the project payment is settled. If Party A has no objection within 3 days after receiving the information, it shall be deemed as agreement. Both parties shall fill in the project settlement form and sign it, and Party A shall pay it to Party B when signing it.
5. The warranty period of this project is to fill in the project warranty from the date of signing by both parties after acceptance.
Seven. Disputes, breach of contract and claims
1. Dispute:
Any dispute arising from this agreement between Party A and Party B shall be settled through negotiation. If negotiation fails, both parties have the right to bring a lawsuit to the court where the project is located. After the dispute occurs, both parties shall perform the contract, keep continuous construction and protect the completed project.
2. Default value:
(1). If the contract cannot be continued due to one party's reasons, that party shall promptly notify the other party to handle the contract termination procedures, and the responsible party shall compensate the other party for the corresponding economic losses.
(2) If Party A uses the finished engineering products in advance or automatically without going through the acceptance formalities, Party A shall be responsible for the losses caused.
(3) If the quality of the project fails to meet the quality standards agreed by both parties due to Party B, Party B shall be responsible for repairing it, and the construction period will not be postponed.
3. Claim:
If Party B fails to carry out the construction as agreed, the quality fails to meet the agreed standards, the construction period fails to meet the agreed requirements, and the quality problems caused by Party B are not repaired in time during the warranty period, Party A may claim compensation from Party B according to the following procedures.
(1). Send a claim notice to the other party within 14 days after the claim event.
(2) Party A (or Party B) shall reply or request Party B (or Party A) to further supplement the claim reasons and evidence within 30 days after receiving the claim notice. If Party A (or Party B) fails to reply within 30 days, it shall be deemed that the claim has been recognized by the other party.
Eight. safe production
1. According to the principle that whoever works is responsible for safety, Party B, as a contractor, must be fully responsible for the safety production in the whole construction process, and Party A has the right to supervise and inspect.
2. Party B shall strictly implement the safety standard management of the construction site according to the relevant regulations, ensure the civilized construction site, take strict protective measures, and bear all responsibilities and expenses caused by poor safety measures.
3. In case of major equipment and personnel casualty accidents, Party B shall immediately report to relevant departments, notify Party A's representative according to relevant regulations, and handle them according to the requirements of relevant government departments. Party A shall provide necessary conditions for rescue, and the expenses shall be borne by Party B. ..
4. Party B shall implement the principle of civilized construction, and must meet the requirements of environmental protection during the construction.
5. In case of damage to the third party, Party B must bear all responsibilities and expenses.
Nine. others
1. This contract shall come into effect after it is formally signed and sealed by both parties.
2. After the completion settlement, Party B delivers the project to Party A, and Party A shall pay the money according to Article 6 of this contract. Unless the relevant warranty clauses are still valid, other clauses of this agreement will be terminated. After the expiration of the warranty period, the relevant warranty terms will be terminated.
3. Number of copies of this contract: two originals, one for each party, which shall be kept separately after being signed and sealed by both parties, and two for each party, with the same legal effect.
4. Matters not covered in this contract shall be settled by both parties through friendly cooperation. If necessary, this agreement can be modified or supplemented in text form.
Party a: (seal) party b: (seal) legal representative (signature): legal representative (signature):
Tel: Tel:
Date of signature: year month date of signature: year month day.
Articles related to simple contract model for interior and exterior wall coatings;
★ Model contract for interior and exterior wall coatings
★ Model Contract for Interior and Exterior Wall Coatings (2)
★ contracting demonstration contract for interior and exterior wall coating engineering.
★ Three contracts for interior and exterior wall coatings.
★ Three simple contracts for exterior wall coating construction.
★ Template for construction contract of interior and exterior wall coatings
★ Model Contract for Interior and Exterior Wall Coatings (2)
★ Internal and external wall coating construction contract template (2)
★ Template for construction contract of interior and exterior wall coatings
★ 3 Model contract for exterior wall coating.