Contractor (Party B):

Party A entrusts Party B with the construction of the bicycle shed renovation project. In accordance with the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, and following the principles of equality, voluntariness, fairness and good faith, Party A and Party B reach an agreement on this project, and hereby sign this contract, the contents of which are as follows:

Article 1: Project Content and Contract Scope

1, project content:

2. Scope of contract:

Article 2: Contract Price and Method

1. Contract price: calculated as per square meter 120 yuan, and calculated as per square meter 200 yuan for bicycle shed, without invoice and any extra expenses.

2. Contracting method: quantity and material contracting is adopted according to the project content.

Article 3: Time limit requirements

The duration of this contract is 20 days, and the commencement date shall be subject to the visa of Party A after foundation pouring.

Article 4: Payment and settlement of project funds

Project cost yuan; Steel structure members of carport; The ground contains excavation, concrete and smooth surface elements. The total project cost is RMB, including RMB for steel structure and RMB for bricklayer. Pay the full amount after the bricklayer's project is completed, pay 95% after the steel structure is qualified, keep 5% as the quality deposit, and pay the balance without quality problems within one year.

Article 5: Project Quality

1. The quality of this project must conform to the specifications, industry standards and steel structure acceptance standards, and the quality level is qualified.

2. If the quality is unqualified, it must be reworked according to the requirements of Party A, and the cost of rework shall be borne by Party B, and the construction period shall not be extended.

3. Party B shall establish a complete quality inspection system, do a good job of self-inspection, and make timely rectification when problems are found.

Article 6: Safe production and civilized construction

Party B must take strict and scientific safety protection measures to carry out civilized construction, ensure construction safety, receive safety education and abide by safety production regulations. If Party B fails to perform the above obligations, resulting in property losses and personal injuries to construction workers or third parties, Party B shall bear the responsibilities and expenses arising therefrom.

Article 7: Obligations of both parties

1. Party A's responsibilities:

(1) is responsible for on-site coordination, management, supervision and inspection of project quality, safety and civilized production.

(2) According to the contract, Party A's project audit shall pay the project payment in time.

2. Party B's responsibilities:

(1) Party B shall, in accordance with the scope and requirements of the contract, complete the specified project contents with good quality and quantity on schedule.

(2) Party B must obey the command of Party A's management personnel, carry out the construction according to the safety technical specifications, and meet the acceptance standards promulgated by the state. In case of violation, the engineer has the right to propose to stop work or be responsible for Party B's rework.

If there are serious problems in the project quality and construction period, or Party A fails to make rectification for many times, Party A may terminate the contract and entrust others to carry out the construction, and Party B shall be responsible for the losses caused thereby.

(3) During the construction period, Party B shall promptly clean up the construction waste to the place designated by Party A to keep the site clean and tidy. Before the project is completed and accepted and handed over, the site should be carefully cleaned so as to clean up the site after work.

Article 8: Project Acceptance

1. If Party B thinks that the project has the conditions for completion acceptance, it shall notify Party A for acceptance.

2. Party A shall organize the project acceptance within the agreed time after receiving the notice. If the site does not meet the qualification requirements or the site is not cleaned up, Party A will put forward rectification opinions and organize acceptance after rectification.

Article 9: Warranty Period and Final Settlement

This project is based on honesty. During the warranty period (calculated from the date of completion acceptance), Party B will earnestly perform its responsibilities. Thoughtful service, on call, to ensure the quality of warranty. If Party B does not cooperate, Party A has the right to ask others to repair it on its behalf, and the expenses shall be borne by Party B. ..

Article 10: supplementary provisions

1. Matters not covered in this contract shall be settled by both parties through consultation. In case of serious differences, both parties shall sign a supplementary agreement.

2. This contract is made in quadruplicate, three for Party A and one for Party B. It shall come into effect after being signed and sealed by both parties. After the contract comes into effect, the project balance will be paid off and the warranty period will automatically terminate.

Party A: (signature and seal)

Party B: (signature and seal)

date month year

Sample 2 of wooden steel structure contract Party A:

Party B:

Signing place: Project place:

In accordance with the Contract Law of People's Republic of China (PRC), the Labor Law of People's Republic of China (PRC), the Regulations on Construction Project Contracts and relevant laws and administrative regulations, both parties have reached the following agreement on the principles of equality, voluntariness, fairness, honesty and credibility:

1. Project content: fabrication and installation of steel roof truss and roof, etc.

2. Calculation method and price: Party A's total project is about 200m2, and Party B's contract is based on the dripping area of the roof, starting from 85 yuan /m2 per square meter (excluding tax). )

Three. Responsibilities of both parties:

Party A shall provide the construction drawings and give a timely reply if there are any changes. Party A shall provide the stacking place for raw materials, power supply, water supply, meals, etc. , and coordinate the crossover operation of field personnel and other problems in construction.

Four. Payment method:

1, Party A and Party B negotiate the commencement date, and settle all the project funds after the project is completed.

2. Party A shall bear all kinds of losses caused by Party B's stoppage or slowdown due to Party A's default in project payment, which will affect the progress of the project.

Verb (abbreviation of verb) safe construction

When entering the site, Party B's staff must abide by the site safety standards and make unified arrangements.

Intransitive verbs start work and postpone it.

Party A and Party B negotiate to start the construction. If the construction is delayed due to Party A's reasons, Party A must inform Party B to postpone the construction and postpone the construction period accordingly. If Party A fails to notify Party B in advance, Party A shall bear the losses caused to Party B thereby. ..

Seven. Project quality

The project quality warranty period is one year. If there is any engineering quality problem, Party B shall repair it in time.

Eight. argue

In case of any dispute during the performance of this contract, both parties shall settle it through consultation. If negotiation fails, it can be submitted to the Arbitration Commission where the project is located for arbitration, or it can be directly brought to the people's court where the project is located.

This contract is made in quadruplicate, with Party A and Party B holding two copies respectively. After the project settlement is completed and the project payment is paid, this contract will automatically become invalid.

Party A: (signature and seal)

Party B: (signature and seal)

date month year

Sample 3 of wooden steel structure contract Party A:

Party B:

According to the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, Party A and Party B, following the principles of equality, voluntariness, fairness, honesty and credibility, have reached the following contract on this project through friendly negotiation:

I. Project name:

Second, the project site selection:

Three. Project content: Construction according to Party A's requirements, including fabrication and installation.

Four. Construction period: year month day to year month day.

5. Contract method: contract fee, crane and tools.

Settlement area of intransitive verb: the area measured after construction.

Seven. Unit price and total price:

Eight, the project quality standard: qualified.

9. Payment method: the workers and tools will pay 10% of the living expenses after they arrive at the site, 40% after the components are manufactured, 60% after the installation, 95% after the project is completed, and the remaining 5% of the project funds will be used as the quality guarantee. The warranty period is one year, and the project will be settled after there is no quality problem.

X. Rights and obligations of both parties.

Party A: (1) Pay the contract price to the contractor in the time and manner specified in the agreement.

(2) Be responsible for the design standards and quality requirements of this project, guide, inspect, supervise and accept, and assist Party B to solve the problems encountered in the construction.

(3) If Party B fails to carry out the construction as required or fails to meet the design requirements, Party A has the right to require it to rework, and give economic punishment or refuse to pay the project fee.

(4) According to the construction needs, provide auxiliary materials such as oxygen, paint, covered electrode, welding wire and gas required by the project.

(5), responsible for night safety, tool storage.

Party B: (1) undertakes to implement and complete the contracted project and remedy the defects in all aspects according to the contract documents, design drawings and Party A's change requirements.

(2) Party B is prohibited from subcontracting or subcontracting the project. If the above behavior is found, Party A has the right to impose economic penalties or terminate the contract. Party B shall bear the losses and impacts caused by changing the construction team. Party B shall not default on the wages of migrant workers.

(3) During the project construction, Party B must seriously implement the rules and regulations for safe construction, and all the responsibilities for safety accidents shall be borne by Party B, and Party A shall not bear any responsibilities.

(4) The articles used by Party B for construction shall be clean and tidy, and materials shall not be wasted or articles shall not be stolen. Once found, the penalty shall be 5 times the value of the articles. If the circumstances are serious, it shall be handed over to judicial organs for handling.

XI。 Liability for breach of contract: Party A and Party B must strictly abide by the provisions of this contract and earnestly perform relevant rights and obligations. If Party B fails to complete the project on time and delays the construction period, the liquidated damages shall be 0.3% of the total price for each day of delay.

12. This agreement is made in duplicate, with each party holding one copy. This agreement shall come into force after being signed or sealed by both parties. Matters not covered in this contract shall be settled by both parties through consultation. If negotiation fails, bring a lawsuit to the local people's court.

Party A: (signature and seal)

Party B: (signature and seal)

date month year

Sample 4 of wooden steel structure contract Party A:

Party B:

1. According to the Contract Law and relevant national standards, Party A and Party B, based on the principles of fairness, reasonableness and mutual benefit, signed the following terms through friendly negotiation:

1, project name:

2. Project location:

Second, the project scope and construction content:

1. Scope of work: civil engineering and steel roof engineering within the scope shown in the construction drawing provided by Party A. ..

2. Construction content: All the nodes shown in the drawings and the requirements for answering questions in the bidding documents and drawings shall be implemented.

Third, the technical conditions

Party A shall provide the construction drawings, which shall be implemented in accordance with the bidding documents, Q&A and construction contract specifications.

Fourth, the price:

The total contract price is 9.8 million yuan.

In words: RMB: nine million eight hundred thousand yuan.

Verb (abbreviation of verb) payment terms

65,438+00% in advance after signing the contract: RMB will be paid after the steel structure column enters the site. After the formal installation of the project, the relevant payment methods will be implemented in accordance with the contract between Party A and the owner.

The responsibilities of both parties of intransitive verbs:

1. Party A's responsibilities:

(1) Before Party B's construction, Party A shall provide the approved construction drawings, and provide the qualified civil bearing surface, pop up the axis, confirm the elevation, and the construction site has the construction conditions.

2. Party B's responsibilities:

(1) Party B shall construct in strict accordance with the overall design requirements.

(2) Party B shall strictly abide by JGJ7-9 1 and GB 50205 standards, and all materials shall meet the design requirements and relevant national standards and specifications.

(3) Party B shall provide qualified products, and the materials, specifications and brands must meet the requirements of the owner.

(4) Party B shall guarantee the construction period and civilized construction, and the project manager must coordinate all matters at the construction site. During the construction, Party B shall be responsible for the accidents caused by Party B.. ..

Seven, time limit for a project:

Party B must complete the fabrication and installation of the civil floor within 70 days of the effective working day. If it exceeds one day, it will be fined 20 yuan, and 65,438 yuan+0,000 yuan will be awarded one day in advance.

Eight, rewards and punishments

1. Party A breaches the contract.

(1) If Party A fails to pay the project payment as agreed in the contract, which leads to the impossibility of construction, it shall be implemented according to Paragraph 4 of Article 26 of the General Conditions.

(2) If Party A fails to pay the settlement price for project completion without justifiable reasons, the general terms and conditions shall prevail.

Paragraph 3 of Article 33 has been implemented.

(3) Party A's failure to perform the contractual obligations causes economic losses to the contractor, the construction period is postponed, and Party B is compensated for the breach of contract.

2. Party B violates this contract.

(1) If Party B fails to complete the project according to the "completion date" agreed in the agreement or the extended construction period agreed by the engineer due to Party B's reasons, it shall be implemented according to paragraph 2 of General Conditions 14.

(2) If the project quality is not up to standard due to Party B's reasons, it shall be implemented according to Article 15 1.

(3) When Party B fails to perform its contractual obligations or fails to perform its obligations according to the terms agreed in the main contract, Party A has the right to deduct the performance bond of Party B..

Nine. accept

After Party B's installation is completed, Party A shall organize relevant units to conduct acceptance inspection according to JGJ7-9 1 and JGJ78-9 1 within 7 days, otherwise it will be deemed as qualified.

X. others

1. This contract is made in quadruplicate, with Party A and Party B holding two copies respectively.

2. Matters not covered shall be settled through negotiation.

3. If both parties disagree with the terms of the contract, the contract signed by Party A and the owner shall prevail.

4. Party A is responsible for supervising the whole process of purchasing colored steel plates and profiles, and has the final decision.

5. Party B shall not default on the wages of migrant workers. If Party A is in arrears, Party B has the right to deduct the deposit and delay the payment of project funds to Party B. ..

6. The contract price includes taxes, which shall be invoiced by Party A at the project location and borne by Party B. ..

Party A (signature):

Party B (signature):

date month year

Sample 5 of wooden steel structure contract Party A:

Party B:

In accordance with the Contract Law and other laws and regulations, and on the principle of equality and mutual benefit, Party A and Party B have reached the following agreement on the production contract of the steel structure main workshop of Sichuan Puchao Color Steel Structure Co., Ltd.:

I. Term of the contract:

The term of the contract is one year, from the effective date of this contract, that is, from the date of signing to 20xx years.

Scope of contract:

1. Party B is responsible for the processing and manufacturing of steel structure members contracted by Party A (from blanking to finished product loading). )

2. Party B is responsible for the normal maintenance and maintenance of mechanical equipment in the main steel structure workshop.

Second, the contract price:

The components of the main steel structure project shall be weighed by Yuan/if required by the customer, both parties shall also weigh them; If the customer asks for theoretical measurement, Party A and Party B also carry out theoretical measurement.

Three. Accounting and payment of contract funds:

1. On 30th of each month, Party A and Party B shall calculate the processing quantity.

2. On the 25th of each month, Party A shall pay Party B a worker's salary of 3,000 yuan/person (on the worker's salary card), and pay Party B a living allowance of 5,000 yuan/month in advance, and the balance shall be settled at the end of the year.

Four. Responsibilities of both parties:

Party A's responsibilities

1. Party A is responsible for providing Party B with mechanical equipment, CNC cutting machine, assembling machine, gantry welding machine, H-beam straightener, shearing machine, rocker turret, shot blasting and painting equipment, electric welding machine and other equipment in the steel structure workshop.

2. Party A shall pay the wages and living expenses of regular workers to Party B on time.

3. Party A shall provide Party B's workers with safety education and training on operating procedures.

Party B's responsibilities

1. Party B shall complete the steel structure engineering production tasks undertaken by Party A on time with good quality and quantity; If the production errors are caused by Party B, Party B shall be responsible for correcting them, and the expenses incurred shall be borne by Party B. If there are major errors, Party B shall bear 50% of the total expenses (the correction expenses shall be priced by the production department).

2. Party B shall obey the management systems of Party A. ..

3. Party B is responsible for the accommodation expenses of its own workers (Party A will provide a Chinese meal, and if it works overtime, Party A will provide dinner).

4. Party B shall ensure that Party A's machinery and equipment can operate normally after the relocation of the factory. And return all tools provided by Party A when Party B enters the factory.

5. During the contract period, Party B shall organize the production according to Party A's production plan and deliver the goods with good quality and quantity on time.

Verb (abbreviation for verb) the rights of both parties

1. If Party B has two consecutive quality or safety accidents in the production process, Party A has the right to terminate this agreement.

2. If Party A fails to pay the contract service fee for two consecutive months, Party B has the right to terminate this agreement.

Six, the purchase cost of work-related injury insurance shall be borne by both parties, and the insured amount is 600,000.

Seven. For matters not covered in this agreement, both parties shall sign a supplementary agreement through negotiation, which has the same legal effect as this agreement. If the agreement fails, they can bring a lawsuit to the local legal arbitration department.

Eight. This agreement is made in duplicate, one for each party.

Nine. This agreement shall come into force as of the date of signature and seal by both parties. If it is necessary to extend this contract after its expiration, this contract has the same effect.

Party A:

Party A: (signature and seal)

Party B: (signature and seal)

date month year