High pressure construction contract 1 Employer (full name): (hereinafter referred to as Party A)
Contractor (full name): (hereinafter referred to as Party B)
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reach an agreement on the construction of this construction project and conclude this contract.
I. Overview of the Project
Project name:
Project location:
Project content:
Source of funds:
Second, the scope of project contracting
Scope of contract:
Third, the term of the contract.
Start date:
Date of completion:
Total calendar days of contract duration.
Fourth, quality standards.
Engineering quality standard: meet the requirements of the current national construction quality acceptance specification and reach the qualified standard.
1, this project implements the current People's Republic of China (PRC) (PRC) municipal engineering construction and acceptance specifications, unified standards for construction quality acceptance of architectural engineering and other relevant standards and specifications.
2, this project according to the current "municipal engineering quality inspection evaluation standard" and so on to reach the qualified level.
Verb (abbreviation of verb) contract price
Amount (in words): tentative: (RMB) ￥ 10,000 yuan.
An intransitive verb constitutes a contract document.
The documents constituting this contract include:
1. Agreement in this contract
2. Special terms and conditions of this contract
3, standards, specifications and related technical documents
4. Cartography
5. Budget book
The written agreement or document on project negotiation and change between both parties shall be regarded as an integral part of this contract.
Seven, the contractor promises to the employer to carry out construction and completion in accordance with the contract, and undertake the project quality warranty responsibility within the quality warranty period.
Eight, the employer promises to the contractor to pay the contract price and other payments in accordance with the time limit and manner agreed in the contract.
Nine. Entry into force of contract
Contract signing time:
Contract signing place:
This contract is agreed by both parties: it will come into effect after being signed and sealed by both parties.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
High-pressure Construction Contract II (full name): (hereinafter referred to as Party A)
Contractor (full name): (hereinafter referred to as Party B)
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reached an agreement on the construction of the 20xx Luocun resettlement project, and hereby concluded this contract:
I. Overview of the Project:
Project name: Three renovation project locations: both sides of Luocun Street Project content: Sources of spraying funds:
Second, the project contracting scope:
Scope of contract:
III. Term of the contract:
Commencement date: June 5, 20xx Completion date: July, 20xx 15. The total contract days are 40 days.
Fourth, the quality standard:
xx
Verb (abbreviation for verb) Contract price:
Spraying materials per square meter 10 yuan, and labor cost is 4 yuan.
The rights and responsibilities of party a:
1. Standard quality of engineering construction, Party B's entry and inspection of various building materials.
2. Strictly monitor the engineering construction procedures and building standards, and have the right to order Party B to rework or stop work for problems such as nonstandard construction procedures and poor quality of engineering standards, and all losses caused thereby shall be borne by Party B..
3. Responsible for organizing relevant personnel to accept and settle the completed project.
4. Be responsible for checking whether the quality of all kinds of building materials entered by Party B is qualified. Unqualified, have the right to prevent unqualified building materials from entering the site.
5. This project is a full mortgage project, and Party A will not pay the project payment before Party B completes it.
Rights and responsibilities of intransitive verb Party B:
1, responsible for organizing a strong construction team to carry out the construction of the project.
2. Carry out construction in strict accordance with Party A's requirements and construction specifications; Put an end to inferior projects and unqualified projects, and put an end to unqualified building materials entering the site.
3. In case of unforeseen projects during the construction, it shall report to Party A in time .. The construction can only be started after Party A confirms it.
4. Accept the construction supervision of Party A and timely rectify the requirements and construction proposed by Party A. ..
5. In the process of construction, we should strengthen management and strictly abide by various construction safety regulations. For example, Party B shall be responsible for all work-related injuries during construction.
Seven. Payment terms:
After the completion of the project is accepted by the relevant departments, the payment will be made after the funds are in place.
Eight, engineering warranty:
The warranty period after the project completion acceptance is one year, and the warranty fund is 65438+ 05% of the project cost. The expenses shall be borne by Party B.. There is no quality problem after the warranty expires, and the warranty money will be paid in one lump sum.
Matters not covered in this contract shall be determined by both parties through consultation.
The above terms and conditions of this contract shall come into effect as of the date of signing by both parties. This contract is made in quintuplicate, each party holds 1 copy. Either party shall not change or change the contents of the contract without authorization, otherwise the changing party shall be responsible for the consequences.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Third Contract for High-pressure Construction: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
I. Responsibility of Party A
1, responsible for three links and one leveling. The site must ensure the conditions of pile driver operation and smooth access.
2. Handling of Party B's peripheral relations and damage caused by pile driver construction. The damage to the surrounding residents shall be handled by Party A, and Party B shall not be liable.
3, send the builder to participate in the site quality management and quantity visa, and is responsible for lofting and drawing.
4. Party A is responsible for exerting pressure and coordinating the relationship between relevant units and the surrounding areas.
II. Responsibility of Party B
1. According to the geological data and the anomalies found on site, Party B shall promptly notify the supervisor and Party A to wait for treatment.
2. Listen to Party A's instructions during construction, and fill in records on time to ensure construction safety.
3. After the completion of the project, Party B shall be responsible for providing the applicant with on-site piling records.
Third, the payment of project funds.
1. This project is a contractor and a contractor. The unit price of piling is PHC-300×75A pile, and the unit price is RMB/m. If short piles less than 8m (including 8m) are required, the short pile fee 10% will be added according to the actual number of short piles. The unit price does not include tips and taxes, and no invoice is issued.
2. If pile delivery is required, only the 30 yuan /m pile delivery fee is calculated.
3. Piling calculation: If it exceeds 1m, Party B shall be responsible. Otherwise, Party A shall be responsible.
4. Pay RMB 654.38+10,000 yuan when entering the site, 80% after 2000m, and pay all the pile money.
5. The cost of pile foundation acceptance inspection shall be borne by Party A, and Party B shall assist in pressure and pressure measurement.
6. If the site is shut down for more than three days due to Party A's reasons, Party A shall be responsible for the living expenses and wages of the workers in 500 yuan/day.
Fourth, the way to solve contract disputes.
Any dispute arising from the performance of this contract between Party A and Party B can be settled through negotiation or coordination. If negotiation or coordination fails, it shall apply to the arbitration department for arbitration or bring a lawsuit to the people's court.
5. This contract is made in duplicate, with each party holding one copy.
This contract shall come into effect after being signed by both parties.
Party A: Tel:
Party B: Tel:
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
4 The Employer of High-pressure Construction Contract (hereinafter referred to as Party A):
Contractor (hereinafter referred to as Party B):
According to People's Republic of China (PRC) Contract Law, People's Republic of China (PRC) Consumer Protection Law, People's Republic of China (PRC) Price Law and other relevant laws and regulations, combined with the specific conditions of this project, Party A and Party B have reached the following agreement on the basis of equality, voluntariness and consensus:
Article 1 General situation of the project:
1. 1 Decorate the construction site:
1.2 building structure: building area of xx square meters. Decoration construction content: See the decoration construction cost table for details.
1.3 project contracting method: _ _ _ _ _ _ _ _ _ _ _ _ _ _.
1.4 contract price: the project cost of this contract is (RMB) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ (excluding tax), and amount in words is _ _ _ _ _ _ _.
1.5 time limit for a project: from _ _ _ _ _ _ _ _ _ _
Article 2 Work of Party A
2. 1 _ _ _ days before the commencement of construction, create conditions for Party B to enter the site for construction, including: demolishing or stacking indoor furniture and furnishings or covering indoor furniture and furnishings that are difficult to move without affecting the construction;
2.2 Provide water and electricity supply during construction;
2.3 Responsible for coordinating the relationship between the construction team and the neighborhood;
2.4 The indoor load-bearing structure shall not be dismantled. If it is really necessary to change the non-load-bearing structure or equipment pipeline of the original building, go through the corresponding examination and approval procedures with the relevant departments;
2.5 During the construction period, if Party A still needs to use part of the living room, it shall be responsible for public security and fire control at the construction site;
2.6 Participate in the supervision of project quality and construction progress, and be responsible for the acceptance of materials entering the site and the completion of the project.
Article 3 Party B's Work
3. 1 During the construction process, the project shall be completed on time with good quality and quantity in strict accordance with the safety construction operation specifications, fire prevention regulations, construction specifications and quality standards;
3.2 Strictly implement the construction site management regulations, and do not disturb the people or pollute the environment;
3.3 protect indoor furniture and furnishings, and ensure the smooth flow of upper and lower water pipes;
3.4 Ensure the cleanliness of the construction site, and be responsible for cleaning up the decoration garbage on the construction site after the project is completed.
Article 4 Engineering Changes
If it is necessary to change the project or construction method, both parties shall reach an agreement through consultation, sign a written change agreement, and adjust the related project cost and construction period.
Article 5 Material supply
5. 1 For the materials and equipment provided by Party A according to the contract, Party A shall notify Party B before the materials arrive at the construction site, and both parties shall jointly accept and handle the handover procedures;
5.2 The materials provided by Party B according to the contract shall ensure the quality. Before the main engineering materials arrive at the construction site, Party B shall notify Party A for joint acceptance.
Article 6 Time limit for a project is delayed
6. 1 If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after being confirmed by Party A;
1, engineering quantity change or design change;
2. Force majeure;
3. Other circumstances that agree to postpone the construction period;
6.2 If the time limit for a project is affected by Party A's failure to complete the work it should be responsible for as agreed in the contract, the time limit for a project will be postponed; If the unqualified materials and equipment provided by Party A affect the project quality, the cost of rework shall be borne by Party A, and the construction period shall be postponed.
6.3 If Party A fails to pay the project payment on schedule, the contract period shall be postponed accordingly.
6.4 If the project cannot be completed on schedule due to Party B's responsibility, the construction period will not be postponed; If there is any problem in the quality of the project due to Party B, the cost of rework shall be borne by Party B, and the construction period shall not be postponed.
Article 7 Project Acceptance and Warranty
In this project, the construction drawings, practice instructions, design changes, and the national Code for Construction and Acceptance of Building Decoration Engineering (JGJ73-9 1) and Unified Standard for Quality Inspection and Evaluation of Building Installation Engineering (GBJ300-88) are the quality acceptance standards. The quality of this project should reach _ _ _ _ _ of the national quality evaluation standard.
7. 1 Both parties agree to check and accept the project quality at the following stages in the construction process:
1, acceptance of concealed works
2, the project mid-term acceptance
3, project completion acceptance
Party B shall notify Party A to participate in the acceptance two days in advance, and fill in the project acceptance form after passing the stage acceptance (see attached table
Four: Decoration Project Acceptance Sheet).
7.2 The warranty period of this project is _ _ _ _ _ _ years from the date of acceptance and signature by both parties. After Party B pays the final payment of the project, it shall sign the acceptance and fill in the project warranty _ _ _ _ _ _ _.
Article 8 Payment method of project funds
8. 1 Both parties agree to pay the project payment as follows:
After this contract comes into effect, Party A will directly pay the project payment to Party B according to the following agreement: As this project is in office decoration, the construction period is tight and special, 50% of the project payment will be paid immediately after the project enters the site, 45% of the total project payment will be paid before the carpenter enters the site for installation, and the remaining 5% will be paid in one lump sum at the end of the project. Mid-term increase in project costs should be paid before the end of the project.
8.2. Half of the project progress refers to: before the paint engineering materials enter the site.
8.3 After the acceptance of the project, Party B proposes the project settlement to Party A, and sends relevant materials to Party A. If Party A has no objection within _ _ _ _ days after receiving the materials, it shall be deemed as consent, and both parties shall fill in the project settlement form (decoration project settlement form); And sign it, and Party A will settle the project balance with Party B when signing it.
Article 9 Liability for breach of contract
9. 1 If either party fails to perform the contract or violates national laws, regulations and relevant policies, the responsible party shall bear the responsibility of being fined or causing economic losses to the other party, and compensate for the economic losses caused to the other party.
9.2 Party A shall be responsible for the losses caused by Party A's early use or unauthorized use of finished engineering products without going through the acceptance formalities;
9.3 If the contract cannot be continued due to one party's reasons, that party shall promptly notify the other party to handle the contract termination procedures, and the responsible party shall compensate the other party for the corresponding economic losses;
9.4 If Party A fails to pay the second (third) project payment on schedule, it shall pay Party B a penalty of 3% of the payable project payment for each day overdue.
9.5 If the quality of the project fails to meet the quality standards agreed by both parties due to Party B, Party B shall be responsible for repairing it, and the construction period will not be postponed;
9.6 If the construction period is delayed due to Party B's reasons, it shall pay liquidated damages to the other party for each day of delay: 3% of the contract amount.
Article 10 Settlement of Contract Disputes If both parties fail to reach an agreement through consultation, the following option shall be adopted for settlement:
① Apply to Jinhua Arbitration Commission for arbitration;
(2) bring a lawsuit to the people's court.
Article 11 Supplementary Provisions
1 1. 1 This contract shall come into effect after being signed (sealed) by both parties.
1 1.2 The project shall not be subcontracted after the signing of this contract.
1 1.3 Party A and Party B directly sign this contract in duplicate, with each party holding one copy.
1 1.4 The contract will be automatically terminated after completion.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
High pressure construction contract 5 Party A: _ _ _ _ _ _ _
Party B: _ _ _ _
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reached an agreement on the construction of this project and signed this contract.
I. Project name:
xx
Second, the project site selection:
xx
Third, the project content:
The total area of slope protection is about 900m3.
The total investment of slope protection is 424 164.42 yuan.
Fourth, the term of the contract.
1. The working day is 1 month, from _ _ _ _ _ _ _ to _ _ _ _ _ _ _ _.
2. In case of irresistible natural circumstances during construction, or Party A requests Party B to suspend work, the construction period will be postponed accordingly.
Verb (abbreviation of verb) quality standard
1. The total contract price of this project is tentatively set at RMB one hundred and thirty-four thousand Wu Bai Wu Bai Liu Shi Yuan only, ￥424 164.42 Yuan.
2. The total contract price is lump sum, including all expenses such as labor, machinery, management, coordination and taxes, and Party A does not need to pay any expenses to Party B. ..
3. Confirmation of engineering quantity: If the engineering quantity changes during the construction, a supplementary agreement or engineering change order shall be signed separately according to the above unit price.
4. Payment method: After the project is completed, 95% of the total contract price will be paid, and the rest will be paid in full within 7 days after the completion acceptance.
An intransitive verb: Party A's obligation.
1. Pay the project payment to the contractor on time.
2. The Employer shall be responsible for solving the problems of city appearance, environmental protection, sanitation, traffic and social order in the civilized production of this project, and the construction period shall be postponed.
Seven. Obligations of Party B
1. Submit the construction plan and progress of this project to Party A within two days after the signing of this contract.
2. Consciously accept the management, supervision and inspection of the construction unit and relevant competent departments to ensure the good safety performance of the construction machinery, and the operators shall take up their posts with the work permit; Accept the daily inspection of the quality of mechanical equipment, materials, valid certificates and employment certificates of operators by the owner and relevant competent departments.
3. In the process of construction, materials, machines and tools shall be stacked according to the unified planning of the owner, and signs shall be set according to the requirements of the owner's standardized construction site, so as to manage the work area and do a good job in public security in the responsible area.
Eight, construction safety
The contractor shall abide by the management regulations on safety production in engineering construction, organize construction in strict accordance with safety standards, and accept the supervision and inspection carried out by industry safety inspectors according to law at any time, and take necessary safety protection measures to eliminate hidden dangers of accidents. The responsibility for the accident caused by the contractor's failure to take all measures and the expenses incurred therefrom shall be borne by the contractor.
Nine. responsibility for breach of contract
1. Party A shall pay the project payment in time as agreed in this contract. In case of overdue, Party A shall pay liquidated damages to Party B, and the amount of liquidated damages shall be calculated according to the bank loan interest rate of the payable amount for the same period.
2. If Party B fails to complete the project on schedule due to reasons other than Party A's or force majeure, Party B shall pay Party A a penalty of 0.5% of the total project amount for each day overdue; If the overdue period exceeds 10 day, Party A has the right to unilaterally terminate the Contract.
X. others
This agreement shall come into effect after being signed or sealed by both parties, in quadruplicate, with each party holding two copies. Matters not covered in this contract shall be settled by both parties through consultation.
Party A: _ _ _ _ Party B: _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
High-voltage Power Construction Contract 6: _ _ _ _ _ _ (hereinafter referred to as Party A)
Contractor: _ _ _ _ _ _ (hereinafter referred to as Party B)
According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, following the principles of equality, voluntariness, openness, honesty and credit, and combining with the actual situation of this project, Party A and Party B have reached the following agreement on the owner's project construction through consultation:
first
Project name: _ _ _ _ _ _ _
second
Project location: _ _ _ _ _ _ _ _ _ _ _
essay
Scope of the contract: _ _ _ _ _ _ _ _ _ _ _ _ _
Article 4
Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Date of Completion: Year Month Day Time limit for a project: _ _ _ _ _ _ days
Article 5,
Contract price: adopted in this project. Outdoor engineering is calculated separately.
The total contract price is _ _ _ _ _ _ _ _ _
Article 6
Responsibility of both parties
1. Party A's responsibilities:
(1) is responsible for technical disclosure and quality inspection on the construction site.
(2) Be responsible for providing Party B with _ _ _ _ copies of construction drawings.
(3) Timely supply of materials stipulated in the contract (when the contractor does not include materials).
(4) Provide Party B with temporary dormitory, water, electricity and all expenses.
(5) Deal with the project settlement in time.
2. Party B's responsibilities:
(1) The construction shall be carried out in strict accordance with the requirements of construction specifications and national quality standards.
(2) The construction must be carried out according to the drawings.
(3) Ensure the construction period and complete the project on schedule.
Article 7
Material supply
1. Main materials: Party A is responsible for providing.
2. Auxiliary materials: Party A is responsible for providing them.
Article 8
Material consumption
The materials consumed in the project shall be subject to the actual occurrence, and the loss shall be calculated by percentage, and the waste shall be returned to Party A..
Article 9
Construction and acceptance
1. Party B shall carry out the construction in strict accordance with the drawings and construction specifications, and accept the inspection and inspection of Party A's representatives and personnel appointed by relevant departments at any time.
2. After the completion of the project, organize relevant departments for acceptance.
Article 10
clearing form
Payment of project funds: pay RMB _ _ _ _ _ per month according to the actual engineering quantity, and pay RMB _ _ _ _ _ _ _ _
Article 11
other
1. This agreement is made in duplicate, with one original and one copy.
2. This agreement shall come into effect as of the date of signature by both parties.
3. After the project payment, this agreement will be automatically terminated.
Article 12
supplementary terms
1. Before Party B starts construction, it shall provide a formal change notice. If Party B starts construction according to the original drawings, and Party A requests changes, all expenses shall be borne by Party A. If Party B fails to meet the technical requirements, it will be reversed free of charge. Party B shall not be responsible for any material quality problems.
2. For extra works (temporary works), Party A shall immediately pay Party B the salary of _ _ yuan per working day, which cannot be paid together with the contracted works.
Party A (signature) _ _ _ _ _ _ Party B (signature) _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _